Legal Advertisements

1. Bid Submission. The City of Santa Barbara (“City”) will accept electronic bids for its Downtown De La Vina Street Safe Crosswalks and Buffered Bike Lanes and the Eastside Community Paseos Project (“Project”), by or before Thursday, January 6, 2022, at 3:00 p.m., through its PlanetBids portal. Bidders must be registered on the City of Santa Barbara’s PlanetBids portal in order to submit a Bid proposal and to receive addendum notifications. Each bidder is responsible for making certain that its Bid Proposal is actually submitted/uploaded with sufficient time to be received by PlanetBids prior to the bid opening date and time. Large files may take more time to be submitted and uploaded to PlanetBids. The receiving time on the PlanetBids server will be the governing time for acceptability of bids. Telegraphic, telephonic, hardcopy, and facsimile bids will not be accepted. If any Addendum issued by the City is not acknowledged online by the Bidder; PlanetBids will prevent the Bidder from submitting a Bid Proposal. Bidders are responsible for obtaining all addenda from the City’s PlanetBids portal. Bid results will be available on PlanetBids.

2. Project Information.

2.1 Location and Description. The Project is located at the below streets and is described as follows: Construct street improvements including curb extensions with ADA-compliant curb ramps, ADA-compliant sidewalk and reconstructed driveways, raised traffic diverters, speed humps, striping, signing, rectangular rapid flashing beacon (RRFB) installation, tree planting and placement of mulch in existing and expanded parkways.

Alisos St. Cota St. Haley St. Ortega St. Cota St. Location From To

E. Canon Perdido St. Cacique St.

Chapala St. Chapala St. Chapala St. N. Soledad Rd. N. Alisos St. N. Cota St. N. Salsipuedes St. Casitas Rd.

E. Canon Perdido and Nopal De La Vina St. De La Vina St. Haley St.

E. Yanonali St. Victoria St. Carrillo St. De La Vina St. Chapala St.

2.2 Time for Final Completion. The Project must be fully completed within 120 working days from the start date set forth in the Notice to Proceed. The City anticipates that the Work will begin on or about April 1, 2022, but the anticipated start date is provided solely for convenience and is neither certain nor binding. N. Canada St. Victoria St. Haley St.

2.3 Estimated Cost. The estimated construction cost is $2,400,000.

3. License and Registration Requirements.

3.1 License. This Project requires a valid California contractor’s license for the following classification(s): Class A General Engineering Contractor. 3.2 DIR Registration. City will not accept a Bid Proposal from or enter into the Contract with a bidder, without proof that the bidder and its Subcontractors are registered with the California Department of Industrial Relations (“DIR”) to perform public work under Labor Code Section 1725.5, subject to limited legal exceptions. 4. Contract Documents. The plans, specifications, bid forms and contract documents for the Project, and any addenda thereto (“Contract Documents”) may be downloaded from City’s website at: planetbids.com/portal/portal.cfm?CompanyID=29959. A printed copy of the Contract Documents may be obtained from CyberCopy Shop, located at 504 N. Milpas Street, Santa Barbara, CA 93103, at (805) 884-6155. 5. Bid Security. The Bid Proposal must be accompanied by bid security of ten percent of the maximum bid amount, in the form of a cashier’s or certified check made payable to City, or a bid bond executed by a surety licensed to do business in the State of California on the Bid Bond form included with the Contract Documents. The bid security must guarantee that within ten days after City issues the Notice of Award, the successful bidder will execute the Contract and submit the payment and performance bonds, insurance certificates and endorsements, and any other submittals required by the Contract Documents and as specified in the Notice of Award.

6. Prevailing Wage Requirements.

6.1 General. This Project is subject to the prevailing wage requirements applicable to the locality in which the Work is to be performed for each craft, classification or type of worker needed to perform the Work, including employer payments for health and welfare, pension, vacation, apprenticeship and similar purposes. 6.2 Rates. The prevailing rates are available on file with the City and at www.dir.ca.gov/DLSR. Each Contractor and Subcontractor must pay no less than the specified rates to all workers employed to work on the Project. The schedule of per diem wages is based upon a working day of eight hours. The rate for holiday and overtime work must be at least time and one-half.

6.3 Compliance. The Contract will be subject to compliance monitoring and enforcement by the DIR, under Labor Code section 1771.4.

7. Performance and Payment Bonds. The successful bidder will be required to provide performance and payment bond for 100% of the Contract Price regardless of the contract dollar amount. 8. Substitution of Securities. Substitution of appropriate securities in lieu of retention amounts from progress payments is permitted under Public Contract Code Section 22300. 9. Subcontractor List. Each bidder must submit, with its Bid Proposal, the name, location of the place of business, California contractor license number, DIR registration number, and percentage of the Work to be performed (based on the Base Bid) for each Subcontractor that will perform work or service or fabricate or install work for the prime contractor in excess of one-half of 1% of the bid price, using the Subcontractor List form included with the Contract Documents. 10. Instructions to Bidders. All bidders should carefully review the Instructions to Bidders before submitting a Bid Proposal.

By: ___________________________________ Date: ________________

William Hornung, CPM, General Services Manager Publication Dates: 1) Wednesday, December 15, 2021 2) Wednesday, December 22, 2021

AN ORDINANCE OF THE COUNCIL OF THE CITY OF SANTA BARBARA APPROVING AND AUTHORIZING THE ACTING SUSTAINABILITY AND RESILIENCE DIRECTOR TO EXECUTE A SECOND AMENDMENT TO THE POWER PURCHASE AGREEMENT WITH ACTION ENERGY, INC. TO ADD FIRE STATION ONE TO THE PROPERTIES SUBJECT TO THE AGREEMENT

The above captioned ordinance was adopted at a regular meeting of the Santa Barbara City Council held on December

7, 2021.

The publication of this ordinance is made pursuant to the provisions of Section 512 of the Santa Barbara City Charter as amended, and the original ordinance in its entirety may be obtained at the City Clerk's Office, City Hall, Santa Barbara, California.

(Seal)

/s/ Sarah Gorman, CMC City Clerk Services Manager

ORDINANCE NO. 6039

STATE OF CALIFORNIA

COUNTY OF SANTA BARBARA

CITY OF SANTA BARBARA ) ) ) ss. ) )

I HEREBY CERTIFY that the foregoing

ordinance was introduced on November 16, 2021 and

adopted by the Council of the City of Santa Barbara at a

meeting held on December 7, 2021, by the following roll call

vote:

AYES:

NOES: Councilmembers Eric Friedman, Alejandra Gutierrez, Oscar Gutierrez, Meagan Harmon, Mike Jordan, Kristen W. Sneddon, Mayor Cathy Murillo

None

ABSENT: None

ABSTENTIONS: None

IN WITNESS WHEREOF, I have hereto set my

hand and affixed the official seal of the City of Santa Barbara

on December 8, 2021.

/s/ Sarah P. Gorman, MMC City Clerk Services Manager

I HEREBY APPROVE the foregoing ordinance

on December 8, 2021.

/s/ Cathy Murillo Mayor

Published December 15, 2021 Montecito Journal

FICTITIOUS BUSINESS

NAME STATEMENT: The following person(s) is/are doing business as: Glamour House, 840 Deerpath Road, Santa Barbara, CA , 93108. Glamour House, INC, 840 Deerpath Road, Santa Barbara, CA , 93108. This statement was filed with the County Clerk of Santa Barbara County on December 2, 2021. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL). FBN No. 2021-0003274. Published December 8, 15, 22, 29, 2021.

FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Casa Mejia, 209 S. Voluntario St. Apt 1, Santa Barbara, CA , 93103. Jeniffern E. Jimenez, 209 S. Voluntario St. Apt 1, Santa Barbara, CA , 93103. This statement was filed with the County Clerk of Santa Barbara County on December 6, 2021. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL). FBN No. 2021-0003288. Published December 8, 15, 22, 29, 2021.

FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Ayurvedic Lifestyle Design, 2020 Las Tunas Rd, Santa Barbara, CA , 93103. Ayurvedic Lifestyle Design, LLC., 2020 Las Tunas Rd, Santa Barbara, CA , 93103. This statement was filed with the County Clerk of Santa Barbara County on November 15, 2021. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL). FBN No. 2021-0003157. Published December 8, 15, 22, 29, 2021.

FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Medina & Thompson, 1071 Alston Road, Santa Barbara, CA , 93108. Marc Alan Gamson, 1071 Alston Road, Santa Barbara, CA , 93108. This statement was filed with the County Clerk of Santa Barbara County on November 15, 2021. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL). FBN No. 2021-0003164. Published December 8, 15, 22, 29, 2021.

FICTITIOUS BUSINESS

NAME STATEMENT: The following person(s) is/are doing business as: Bright Solutions Glass Tinting, 233 Big Sur Drive, Goleta, CA , 93117. Jeancarlo Parra, 233 Big Sur Drive, Goleta, CA , 93117. This statement was filed with the County Clerk of Santa Barbara County on November 22, 2021. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL). FBN No. 20210003212. Published November 24, December 1, 8, 15, 2021.

FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Flame Chix, 209 South Voluntario St. Apt 1, Santa Barbara, CA 93013. Keith H. Morrison, 1692 Las Canoas Road, Santa Barbara, CA, 93105. This statement was filed with the County Clerk of Santa Barbara County on November 17, 2021. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL). FBN No. 20210003182. Published November 24, December 1, 8, 15, 2021.

FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Pollo Flameado, 209 South Voluntario St. Apt 1, Santa Barbara, CA 93013. Keith H. Morrison, 1692 Las Canoas Road, Santa Barbara, CA, 93105. This statement was filed with the County Clerk of Santa Barbara County on November 17, 2021. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL). FBN No. 20210003180. Published November 24, December 1, 8, 15, 2021.

NOTICE OF PETITION TO ADMINISTER ESTATE OF: Mi-

chael Shawn Summers. Case Number: 21PR00511. To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both: A Petition for Probate has been filed by: Gary J. Summers in the Superior Court of California, County of Santa Barbara. The petition requests authority to administer the estate under the Independent Administration of Estates Act. The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority. A hearing on the petition will be held in this court as follows: 1/13/2022 at 9 am in Dept. 5, 1100 Anacapa Street, Santa Barbara, CA 93101. If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court. You may want to consult with an attorney knowledgeable in California law. You may examine the file kept by the court. A Request for Special Notice is available from the court clerk. Attorney for the petitioner: Kendall A. VanConas, 805988-9886. Filed November 24, 2021 by Darrel E. Parker, Executive Officer. Published 12/8, 12/15, 12/22, 12/29

NOTICE IS HEREBY GIVEN that sealed bids will be received via electronic transmission on the City of Santa Barbara PlanetBids portal site until the date and time indicated below at which time they will be publicly opened and posted for:

BID NO. 5937

DUE DATE & TIME: JANUARY 19, 2022 UNTIL 3:00 P.M.

MAINTENANCE & REPAIRS OF TRASH RECYCLING CONTAINERS

Scope of Work: This project requires a contractor to un-install container and take to the City’s Annex Yard located at 401 E. Yanonali Street, Santa Barbara. Once refurbished, contractor will pick up the containers from the City’s annex yard and re-install the containers in the original locations.

Bidders must be registered on the city of Santa Barbara’s PlanetBids portal in order to receive addendum notifications and to submit a bid. Go to PlanetBids for bid results and awards. It is the responsibility of the bidder to submit their bid with sufficient time to be received by PlanetBids prior to the bid opening date and time. The receiving deadline is absolute. Allow time for technical difficulties, uploading, and unexpected delays.

Late or incomplete Bid will not be accepted.

If further information is needed, contact Caroline Ortega, Senior Buyer at (805) 564-5351or email: COrtega@santabarbaraca.gov

FAIR EMPLOYMENT PRACTICE ACT Contractor agrees in accordance with Section 1735 and 1777.6 of California Labor Code, and the California Fair Employment Practice Act (Sections 1410-1433) that in the hiring of common or skilled labor for the performance of any work under this contract or any subcontract hereunder, no contractor, material supplier or vendor shall, by reason of age (over 40), ancestry, color, mental or physical disability, sex, gender identity and expression, marital status, medical condition (cancer or genetic characteristics), national origin, race, religious belief, or sexual orientation, discriminate against any person who is qualified and available to perform the work to which such employment relates. The Contractor further agrees to be in compliance with the City of Santa Barbara’s Nondiscriminatory Employment Provisions as set forth in Chapter 9 of the Santa Barbara Municipal Code.

BONDING Bidders are hereby notified that a Payment Bond in the amount of 100% of the bid total will be required from the successful bidder for bids exceeding $25,000. The bond must be provided with ten (10) calendar days from notice of award and prior to the performance of any work. The bond must be signed by the bidder and a corporate surety, who is authorized to issue bonds in the State of California. If the renewal options are exercised, new

bonds shall be provided.

Bidders are hereby notified that a separate Performance Bond in the amount of 100% of the bid total will be required from the successful bidder for bids exceeding $25,000. The bond must be provided with ten (10) calendar days from notice of award and prior to the performance of any work. The bond must be signed by the bidder and a corporate surety, who is authorized to issue bonds in the State of California. If the renewal options are

exercised, new bonds shall be provided.

PREVAILING WAGE, APPRENTICES, PENALTIES, & CERTIFIED PAYROLL In accordance with the provisions of Labor Code § 1773.2, the Contractor is responsible for determining the correct prevailing wage rates. However, the City will provide wage information for projects subject to Federal Davis Bacon requirements. The Director of Industrial Relations has determined the general prevailing rates of wages and employer payments for health, welfare, vacation, pensions and similar purposes applicable, which is on file in the State of California Office of Industrial Relations. The contractor shall post a copy of these prevailing wage rates at the site of the project. It shall be mandatory upon the contractor to whom the contract is awarded and its subcontractors hired to pay not less than the said prevailing rates of wages to all workers employed by him in the execution of the contract (Labor Code § 1770 et seq.). Prevailing wage rates are available at http://www.dir.ca.gov/oprl/PWD/index.htm

It is the duty of the contractor and subcontractors to employ registered apprentices and to comply with all aspects of Labor Code § 1777.5.

There are penalties required for contractor’s/subcontractor’s failure to pay prevailing wages and for failure to employ apprentices, including forfeitures and debarment under Labor Code §§ 1775, 1776, 1777.1, 1777.7 and 1813.

Under Labor Code § 1776, contractors and subcontractors are required to keep accurate payroll records. The prime contractor is responsible for submittal of their payrolls and those of their subcontractors as one package. Payroll records shall be certified and made available for inspection at all reasonable hours at the principal office of the contractor/subcontractor pursuant to Labor Code § 1776.

The contractor and all subcontractors under the direct contractor shall furnish certified payroll records directly to the Labor Compliance

Unit and to the department named in the Purchase Order/Contract at least monthly, and within ten (10) days of any request from any request from the City or the Labor Commissioner in accordance with Section 16461 of the California Code of Regulations. Payroll records shall be furnished in a format prescribed by section 16401 of Title 8 of the California Code of Regulations, with use of the current version of DIR's “Public Works Payroll Reporting Form” (A-1-131) and “Statement of Employer Payments” (DLSE Form PW26) constituting presumptive compliance with this requirement, provided the forms are filled out accurately and completely. In lieu of paper forms, the Compliance Monitoring Unit may provide for and require the electronic submission of certified payroll reports. The provisions of Article 2 and 3, Division 2, Chapter 1 of the Labor Code, State of California, are made by this reference a part of this quotation or bid.

A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in this chapter, unless currently licensed to perform the work and registered pursuant to Labor Code § 1725.5 without limitation or exception. It is not a violation of this section for an unlicensed contractor to submit a bid that is authorized by Section 7029.1 of the Business and Professions Code or by Section 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded.

This project is subject to compliance monitoring and enforcement by the Department of Industrial Relations.

CERTIFICATIONS In accordance with California Public Contracting Code § 3300, the City requires the Contractor to possess a valid California B-General Building contractor’s license at time the bids are opened and to continue to hold during the term of the contract all licenses and certifications required to perform the work specified herein.

CERTIFICATE OF INSURANCE Contractor must submit to the contracted department within ten (10) calendar days of an order, AND PRIOR TO START OF WORK, certificates of Insurance naming the City of Santa Barbara as Additional Insured in accordance with the attached Insurance Requirements.

_______________________________ William Hornung, C.P.M. General Services Manager Published 12/15/21 Montecito Journal