Corporate Interiors by MARK M G

PROJECT

CANCER RESEARCH INSTITUTE

ELEVATOR LOBBY

29 BROADWAY, 4TH FLOOR NEW YORK, NY 10006

NOTICE IT IS A VIOLATION OF THE LAW FOR ANY PERSON TO ALTER THESE DOCUMENTS IN ANY WAY. THIS DRAWING, PREPARED FOR THE SPECIFIC PROJECT INDICATED, IS AN INSTRUMENT OF SERVICE AND THE PROPERTY OF JANKO RASIC ARCHITECTS (JRA). INFRINGEMENTS OR ANY USE OF THIS DRAWING FOR ANY OTHER PROJECT IS PROHIBITED. ANY ALTERATION OR REPRODUCTION OF THIS DOCUMENT IS ALSO PROHIBITED WITHOUT WRITTEN CONSENT OF JRA. USE OF THIS FILE INCLUDING MODIFICATIONS IS AT THE SOLE RISK AND LIABILITY OF THE USER. THE USER SHALL TO THE FULLEST EXTENT THE LAW HOLD JRA HARMLESS FROM ANY CLAIMS, LIABILITIES, DAMAGES, LOSSES, JUDGMENTS, COST AND EXPENSES INCLUDING LEGAL FEES THAT MAY BE INCURRED BY JRA AS A RESULT OF ANY AND ALL USE OF THE CAD DATA, INCLUDING AND NOT LIMITED TO, ANY ALTERATIONS, MODIFICATIONS, DEVIATIONS FROM OR ADDITIONS TO THE DRAWINGS. THE CONTRACTOR IS RESPONSIBLE FOR: CONFIRMING AND CORRELATING ALL QUANTITIES AND DIMENSIONS.

KEY PLAN

SCALE: NO SCALE

DE01.00

INSTALL TWO (2) SPRINKLER HEADS ON CORRIDOR SIDE OF GLASS DOOR / PARTITION

CLOS. PLOT PLAN LOCATION: BLOCK: LOT: ZONE: MAP:

29 Broadway - 4th Floor NEW YORK, NY 10006 20 01 C5-5 12b

PUBLIC CORRIDOR 1HR FIRE RATED 1 MARK

BROAD WAY

TRINITY PL

WOOD FPSC

5.15.17 DATE

DATE: PROJECT NO: CAD DWG FILE: DRAWN BY: CHECKED BY: SCALE: SHEET TITLE

FULL HEIGHT GLASS DOOR COMPLETE WITH HARDWARE AND DISTRACTION MARKS AS REQUIRED BY CODE

INSTALL THREE (3) SPRINKLER HEADS ON INSIDE OF GLASS DOOR / PARTITION

FOR CCD1 DESCRIPTION 5.15.17 1505-16 MG HG AS NOTED

4TH FLOOR GLASS TENANT ENTRY DOOR

AREA OF WORK

PARTIAL 4TH FLOOR PLAN SCALE: 1/4"=1'-0"

PROJECT

C NI

DOMINGO GONZALES ASSOCIATES

29 BROADWAY, 3RD FLOOR NEW YORK, NY 10006

ELEVATOR LOBBY

WOOD DOOR TO REMAIN, FPSC

COMMON CORRIDOR

USE OF THIS FILE INCLUDING MODIFICATIONS IS AT THE SOLE RISK AND LIABILITY OF THE USER. THE USER SHALL TO THE FULLEST EXTENT THE LAW HOLD JRA HARMLESS FROM ANY CLAIMS, LIABILITIES, DAMAGES, LOSSES, JUDGMENTS, COST AND EXPENSES INCLUDING LEGAL FEES THAT MAY BE INCURRED BY JRA AS A RESULT OF ANY AND ALL USE OF THE CAD DATA, INCLUDING AND NOT LIMITED TO, ANY ALTERATIONS, MODIFICATIONS, DEVIATIONS FROM OR ADDITIONS TO THE DRAWINGS. THE CONTRACTOR IS RESPONSIBLE FOR: CONFIRMING AND CORRELATING ALL QUANTITIES AND DIMENSIONS.

KEY PLAN

SCALE: NO SCALE

DE01.00

PUBLIC CORRIDOR 1HR FIRE RATED

INSTALL TWO (2) SPRINKLER HEADS ON EACH SIDE OF NEW GLASS DOOR

PLOT PLAN

TRINITY PL

BLOCK: LOT: ZONE: MAP:

29 Broadway - 3rd Floor NEW YORK, NY 10006 20 01 C5-5 12b

INSTALL TWO (2) SPRINKLER HEADS ON EACH SIDE OF NEW GLASS DOOR

NEW FULL HEIGHT GLASS DOOR AND SIDELIGHTS COMPLETE WITH HARDWARE AND DISTRACTION MARKS AS REQUIRED BY CODE

NIC NIC

BROAD WAY

LOCATION:

1 MARK

5.15.17 DATE

DATE: PROJECT NO: CAD DWG FILE: DRAWN BY: CHECKED BY: SCALE: SHEET TITLE

FOR CCD1 DESCRIPTION 5.15.17 1505-12 MG HG AS NOTED

3RD FLOOR GLASS TENANT ENTRY DOOR

NIC

AREA OF WORK

PARTIAL 3RD FLOOR PLAN SCALE: 1/4"=1'-0"

Architect:

MEP Engineer: KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

Expediter: BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

CANCER RESEARCH INSTITUTE 29 BROADWAY, 4TH FLOOR NEW YORK, NY 10006

Issue:

ISSUED FOR BID 04.28.2017

SHEET TITLE

COVER SHEET SEAL & SIGNATURE

02.08.2017 1505-16 KR HG NTS

T-001.00 1505-16CV04-TS-001.00

014

ABBREVIATIONS A A/C ACCES ACOUS ACT ADJ ADJUST AFF AL ALT ANNUNC ANOD APPL APPROX ARCH AUTO AVG

NYC DEPARTMENT OF BUILDINGS - GENERAL NOTES

AIR CONDITIONING ACCESSORY ACOUSTIC ACOUSTIC CEILING TILE ADJACENT ADJUSTABLE ABOVE FINISHED FLOOR ALUMINUM ALTERNATE ANNUNCIATOR ANODIZED APPLIANCE APPROXIMATE (LY) ARCHITECT (URAL) AUTOMATIC AVERAGE

B BDRM BLDG BOLLD BD BLKG BO BOH BRDLM BRZ BU

BEDROOM BUILDING BOLLARD BOARD BLOCKING BOTTOM OF BACK OF HOUSE BROADLOOM BRONZE BUILT UP

C CAB CPT CEM CER CLG CLR COATG COILG COL CONC CONSTR CONT CONTR COORD COV CMU

CABINET CARPET CEMENT (ITIOUS) CERAMIC CEILING CLEAR COATING COILING COLUMN CONCRETE CONSTRUCTION CONTINUOUS (ATION) CONTRACT (OR) COORDINATE COVER CONCRETE MASONRY UNIT

D DBL DEPT DET/DTL DF DIA DIFF DIM DISP DIV DN DR DSCON DWG DWR

E E ELAST ELEC ELEV EMBED ENGR ENTR EQ EQUIP EWC EX/EXIST EXP JT EXPS EXT

EXISTING ELASTOMETRIC ELECTRIC (AL) ELEVATION EMBEDD (ED) (ING) ENGINEER (ED) ENTRANCE EQUAL EQUIPMENT ELECTRIC WATER COOLER EXISTING EXPANSION JOINT EXPOSED EXTERIOR

F FA FAB FD FE FE&C FHC FIN FLDG FPLC FR FRMG FXD FXTR FLR FLUOR FURN FWC

FIRE ALARM FABRICATION FLOOR DRAIN FIRE EXTINGUISHER FE AND CABINET FIRE HOSE CABINET FINISH (ED) FOLDING FIREPLACE FIRE RAT (ING) (ED) FRAMING FIXED FIXTURE FLOOR (ING) FLUORESCENT FURNITURE FABRIC WALL COVERING

G GA GF GFRC GFRG GFRP GL GR GWB/GYP

INFORMATION INSTRUMENTAL INSULATION INTERLOCK(ING) INTERIOR INFILTRATION

J JAN

LAVATORY POUND/POUNDS LANDLORD LIGHT LEVELING LOUVER

M MAX MFD MFR MECH MET/MTL MEMB MEZZ MIN MISC MLWK MOIST MOT MR MRB MRF MRT MTD

HEAD HARDWOOD HARDWARE HOLLOW METAL HORIZONTAL HEIGHT HEATING, VENTILATING, AND AIR CONDITIONING

I INFO INSTRUM INSUL INTLK INT INFILTR

KITCHEN

L LAV LB/LBS LL LT LVLG LVR

GAUGE GLASS FIBER GF REINFORCED CONCRETE GF REINFORCED GYPSUM GF REINFORCED PLASTER GLASS GRAD (E) (ING) GYPSUM

H HD HDWD HDWE HM HORIZ HT HVAC

DOUBLE DEPARTMENT DETAIL DRINKING FOUNTAIN DIAMETER DIFFUSER DIMENSION DISPENSER DIVISION DOWN DOOR DISCONNECT DRAWING DRAWER

K KIT

MAXIMUM MANUFACTURED MANUFACTURER MECHANICAL METAL MEMBRANE MEZZANINE MINIMUM MISCELLANEOUS MILLWORK MOISTURE MOTOR (IZED) MARBLE MARBLE BASE MARBLE FLOOR MARBLE THRESHOLD MOUNTED

N NIC NO NTS

NOT IN CONTRACT NUMBER NOT TO SCALE

O OC ORNA OVFL OVHD OPNG OPR

ON CENTER ORNAMENTAL OVERFLOW OVERHEAD OPENINGS OPERABLE

P PB PT PTN PEDTR PBD PNL POLYST PORT PREFIN PREFAB PL/PLAM PLAS PLSTC PLYWD PMET PNL PRTECN PSS

PAINTED BASE PAINT PARTITION PEDESTRIAN PARTICLE BOARD PANEL POLYSTYRENE PORTABLE PREFINISHED PREFABRICATED PLASTIC LAMINATE PLASTER PLASTIC PLYWOOD PAINTED METAL PANEL PROTECTION POLISHED STAINLESS STEEL

R R RB RBR RCP RDR RECES RECPT

RELOCATE RUBBER BASE RUBBER REFLECTED CEILING PLAN READER RECESSED RECEPTACLE

S SCR SECT SECUR SF SGL SHORG SIM SS SST ST STD STL STRFR STRUCT SURF SUSP SYS

SCRIBE SECTION SECURITY SQUARE FEET SINGLE SHORING SIMILAR SIMULATED STONE STAINLESS STEEL STONE STANDARD STEEL STOREFRONT STRUCTURE/STRUCTURAL SURFACE SUSPENDED SYSTEMS

T TBD TEL THK TLT TO TRAF TRANS TRTD T&G TYP

TO BE DETERMINED TELEPHONE THICK TOILET TOP OF TRAFFIC TRANSPARENT TREATED TONGUE AND GROOVE TYPICAL

THE MINIMUM WIDTH OF ALL CORRIDORS SHALL BE 3'-8". EXISTING AND NEW DIRECTIONAL SIGNS AND EXIT LIGHTS ARE TO COMPLY WITH SECTIONS C27-381 THROUGH 386 OF THE NYC BUILDING CODE, LL 76. ENTIRE PROJECT FLOOR AREA IS MECHANICALLY VENTILATED AS PER SECTION C27-776, RS-1 THROUGH 5, RS-16 OF THE NYC BUILDING CODE, LL76. ALL WOOD USED WILL BE FIREPROOFED IN ACCORDANCE WITH THE REQUIREMENTS OF SECTIONS 7.2.3.1 AND 10.9.2.6 OF THE BUILDING CODE. SUSPENDED CEILINGS TO CONFORM WITH SECTION 8.4.10.5 OF THE NEW YORK CITY BUILDING CODE USING METAL HANGERS, RUNNERS AND PURLINS AS PER CLASS 1 FIREPROOF BUILDINGS. REFER TO DETAIL FILED HEREWITH. ALL DOORS TO BE 3' BY 7' MINIMUM. THERE WILL BE NO CHANGE TO USE, EGRESS OR OCCUPANCY AS A RESULT OF THIS APPLICATION. LOCAL LAW 5 WILL NOT BE AFFECTED BY THIS APPLICATION BECAUSE: ( ) THE ENTIRE FLOOR IS LESS THAN 7,500 SQ. FT. (X) THE ENTIRE FLOOR IS SPRINKLERED. ( ) THE BUILDING IS NOT CENTRALLY AIR CONDITIONED. ( ) THE AREA OF WORK IS LESS THAN 40' ABOVE CURB LEVEL. ( ) THE AREA OF WORK IS WITHIN AN EXISTING COMPARTMENT. ( ) THE AREA OF WORK IS COVERED BY AREA SMOKE DETECTION. ( ) LOCAL LAW 5 WILL BE REVIEWED UNDER SEPARATE APPLICATION. FLOOR HAS A ( ) SINGLE (X) MULTI-TENANT OCCUPANCY. NO CHANGE TO USE EGRESS OR OCCUPANCY UNDER THIS APPLICATION, SAFETY NOTES ALL CONSTRUCTION WORK WILL BE CONFINED TO THE AREA OF WORK AS DEFINED BY THE DRAWINGS AND WILL NOT CREATE DUST, DIRT OR OTHER SUCH INCONVENIENCES TO OTHER TENANTS. THE CONSTRUCTION OPERATION WILL NOT BLOCK ANY MEANS OF EGRESS. THE CONSTRUCTION OPERATION WILL BE CONFINED TO NORMAL WORKING HOURS (I.E., 7AM TO 6PM, MONDAY THRU FRIDAY) EXCEPT LEGAL HOLIDAYS OR AS DIRECTED BY BUILDING MANAGEMENT. THERE WILL BE NO ONE OCCUPYING THE AREA TO BE RENOVATED DURING THE COURSE OF THE WORK. THE BUILDING MANAGER IS TO BE ADVISED OF ANY INTERRUPTION IN HEATING, WATER OR ELECTRICAL SERVICE.

NOTES

U UNDRLAY UTIL UON

UNDERLAYMENT UTILITY UNLESS OTHERWISE NOTED

V VB VCT VEH VERT VIF VWC

VINYL BASE VINYL COMPOSITION TILE VEHICLE VERTICAL VERIFY IN FIELD VINYL WALLCOVERING

W W/ WD WDC WDW WH W/O WT WTRPRF

2. 3. 4. 5. 6.

WITH WOOD WINDOW CASING WINDOW WINDOW HEAD WITHOUT WEIGHT WATERPROOFING

PER THE BUILDING CODE, "NOTICE OF COMMENCEMENT OF WORK" - AT LEAST 24 HOURS WRITTEN NOTICE SHALL BE GIVEN TO THE COMMISSIONER BEFORE THE COMMENCEMENT OF ANY WORK FOR WHICH A PERMIT HAS BEEN ISSUED. BEFORE ANY WORK IS COMMENCED ON AN ITEM OF CONSTRUCTION REQUIRING CONTROLLED INSPECTION, ALL PERSONS RESPONSIBLE FOR SUCH CONTROLLED INSPECTION SHALL BE NOTIFIED IN WRITING AT LEAST 72 HOURS PRIOR TO SUCH COMMENCEMENT. WORK FILED ON THIS APPLICATION INVOLVES NO CHANGE IN USE, EGRESS AND OCCUPANCY. ALL ELECTRICAL WORK TO BE FILED BY ELECTRICAL CONTRACTOR AT B.E.C. ALL WOOD TO BE USED IN THE CONSTRUCTION SHALL BE FIRE RETARDANT TREATED WOOD IN ACCORDANCE WITH SECTION C27-328 OF THE NEW YORK CITY BUILDING CODE. HUNG CEILING CONSTRUCTION SHALL COMPLY WITH SECTION C27-350 AND RS5-16. ALL FLOOR AND WALL FINISHES TO COMPLY WITH THE MINIMUM REQUIREMENTS FOR INTERIOR FINISH CLASS, FLAME SPREAD RATINGS AND SMOKE DENSITY PER SECTION C27-348 THRU C27-351 & TABLE 5-4. ATTACHMENT OF FINISHES TO BE PER SECTION C27-348(F).

ADA NOTES 1. ALL NEW AND RELOCATED DOORS TO BE MINIMUM 2'-10" WIDE WITH PROPER CLEARANCES. 2. AUTOMATIC DOOR CLOSING DEVICES MUST BE HANDICAP APPROVED TYPE AS MANUFACTURED BY LCN OR EQUIVALENT. 3. ALL NEW TRIMMED OPENINGS TO BE MINIMUM 2'-8" WIDE. 4. 5% OF NEW WORKSTATIONS SHALL BE HANDICAP USABLE WITH MINIMUM 2'-8" CLEAR PASSAGE POINT.

JANITOR

(b) HINGED DOOR

(d) FOLDING DOOR

18" MIN, 24 PREFERRED

(e) MAXIMUM DOORWAY DEPTH

CLEAR DOORWAY WIDTH AND DEPTH

Y X

NOTE: X=12" MIN IF DOOR HAS BOTH A LATCH AND A CLOSER

48" MIN

PUSH SIDE

54" MIN 48" MIN

Y=42" MIN

Y=48" MIN

Y=42" MIN

(a) FRONT APPROACHES SWINGING DOORS

X=24" MIN

PULL SIDE

PUSH SIDE

NOTE: X=36" MIN IF Y=60" X=42" MIN IF Y=54"

42" MIN

54" MIN

PULL SIDE

24" MIN

42" MIN

(a) DETAIL

PUSH SIDE

PULL SIDE

32" MIN CLEAR

48" MIN

32" MIN CLEAR

60" MIN

32" MIN CLEAR

24" MIN

32" MIN CLEAR

48" MIN

Y=48" MIN IF DOOR HAS 4' A LATCH8'AND A BOTH CLOSER

NOTE: Y=54" MINIMUN IF DOOR HAS CLOSER.

16'

X=48" MIN IF DOOR HAS A CLOSER

(d) FRONT APPROACHSLIDING AND FOLDING DOORS

(e) SLIDE SIDE APPROACHSLIDING AND FOLDING DOORS

(f) LATCH SIDE APPROACHSLIDING AND FOLDING DOORS

(b) HINGE SIDE APPROACHES - SWINGING DOORS

DRAWING INDEX

SPECIAL INSPECTIONS

ARCHITECTURAL

( ) STRUCTURAL STEEL - WELDING ( ) STRUCTURAL STEEL - DETAILS ( ) STRUCTURAL STEEL - HIGH STRENGTH BOLTING ( ) STRUCTURAL COLD-FORMED STEEL ( ) CONCRETE - CAST-IN-PLACE ( ) CONCRETE - PRECAST ( ) CONCRETE- PRESTRESSED ( ) MASONRY ( ) WOOD - INSTALLATION OF HIGH LOAD DIAPHRAGMS ( ) WOOD INSTALLATION OF METAL-PLATE- CONNECTED TRUSSES ( ) WOOD- INSTALLATION OF PREFABRICATED I-JOISTS ( ) SUBGRADE INSPECTION ( ) SUBGRADE CONDITIONS - FILL PLACEMENT & IN-PLACE DENSITY ( ) SUBSURFACE - INVESTIGATIONS (BORINGS/TEST PITS) ( ) DEEP FOUNDATION ELEMENTS ( ) HELICAL PILES (BB #2014-014) ( ) VERTICAL MASONRY FOUNDATION ELEMENTS ( ) WALL PANELS, CURTAIN WALLS, AND VENEERS (X) SPRAYED FIRE-RESISTANT MATERIALS ( ) MASTIC AND INTUMESCENT FIRE-RESISTANT COATINGS ( ) EXTERIOR INSULATION AND FINISH SYSTEMS (EIFS) ( ) ALTERNATIVE MATERIALS - OTCR BUILDINGS BULLETIN #_______ ( ) SMOKE CONTROL SYSTEMS (X) MECHANICAL SYSTEMS ( ) FUEL-OIL STORAGE AND FUEL-OIL PIPING SYSTEMS ( ) HIGH PRESSURE STEAM PIPING (WELDING) ( ) HIGH TEMPERATURE HOT WATER PIPING (WELDING) ( ) HIGH PRESSURE FUEL-GAS PIPING (WELDING) ( ) STRUCTURAL STABILITY - EXISTING BUILDINGS ( ) EXCAVATIONS - SHEETING, SHORING, AND BRACING ( ) UNDERPINNING ( ) MECHANICAL DEMOLITION ( ) RAISING AND MOVING A BUILDING ( ) SOIL PERCOLATION TEST -PRIVATE ON-SITE STORM WATER DRAINAGE DISPOSAL SYSTEMS, AND DETENTION FACILITIES ( ) PRIVATE ON-SITE STORM WATER DRAINAGE DISPOSAL SYSTEMS, AND DETENTION FACILITIES INSTALLATION ( ) INDIVIDUAL ON-SITE PRIVATE SEWAGE DISPOSAL SYSTEMS INSTALLATION ( ) SOIL PERCOLATION TEST - INDIVIDUAL ON-SITE PRIVATE SEWAGE DISPOSAL SYSTEMS (X) SPRINKLER SYSTEMS ( ) STANDPIPE SYSTEMS ( ) HEATING SYSTEMS ( ) CHIMNEYS (X) FIRE-RESISTANT PENETRATIONS AND JOINTS ( ) ALUMINUM WELDING ( ) FLOOD ZONE COMPLIANCE (ATTACH FEMA ELEVATION/DRY FLOODPROOFING CERTIFICATE WHERE APPLICABLE) ( ) LUMINOUS EGRESS PATH MARKINGS ( ) EMERGENCY AND STANDBY POWER SYSTEMS (GENERATORS) ( ) POST-INSTALLED ANCHORS (BB#2014-012, 2014-013) ( ) SEISMIC ISOLATION SYSTEMS ( ) CONCRETE DESIGN MIX ( ) CONCRETE SAMPLING AND TESTING

T-001.00 A-001.00 A-002.00 A-003.00 A-004.00 A-101.00 A-102.00 A-103.00 A-104.00 A-201.00 A-202.00 A-501.00 A-502.00 A-601.00

COVER ABBREVIATIONS, DRAWING INDEX, ADA INFO, & GENERAL NOTES GENERAL NOTES GENERAL NOTES & GRAPHIC SYMBOLS GENERAL NOTES CONSTRUCTION PLAN REFLECTED CEILING POWER AND SIGNAL PLAN FINISH PLAN INTERIOR ELEVATIONS 1 INTERIOR ELEVATIONS 2 DETAILS 1 DETAILS 2 DOOR SCHEDULE

ARCHITECT

MEP ENGINEER:

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

EXPEDITER:

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

CLIENT:

PROGRESS INSPECTION ITEMS ( ) PRELIMINARY ( ) FOOTING AND FOUNDATION ( ) LOWEST FLOOR ELEVATION (ATTACH FEMA FORM) ( ) STRUCTURAL WOOD FRAME (X) ENERGY CODE COMPLIANCE INSPECTIONS ( ) FIRE-RESISTANCE RATED CONSTRUCTION ( ) PUBLIC ASSEMBLY EMERGENCY LIGHTING (X) FINAL

ENERGY CODE PROGRESS INSPECTION

ADA INFORMATION

NYC DEPARTMENT OF BUILDINGS - LIST OF INSPECTIONS

( ) PROTECTION OF FOUNDATION INSULATION ( ) INSULATION PLACEMENT AND R VALUES ( ) FENESTRATION THERMAL VAULES AND RATINGS ( ) FENESTRATION RATINGS FOR AIR LEAKAGE ( ) FENESTRATION AREAS ( ) AIR SEALING AND INSULATION- VISUAL ( ) AIR SEALING AND INSULATION- TESTING ( ) PROJECTION FACTORS ( ) LOADING DECK WEATHER SEALS ( ) VESTIBULES ( ) FIREPLACES ( ) DAMPERS INTEGRAL TO BUILDING ENVELOPE ( ) HVAC AND SERVICE WATER HEATING EQUIPMENT ( ) HVAC AND SERVICE WATER HEATING SYSTEM CONTROLS (X) DUCT PLENUM AND PIPING INSULATION AND SEALING ( ) DUCT LEAKAGE AND TESTING ( ) ELECTRICAL METERING ( ) LIGHTING IN DWELLING UNITS (X) INTERIOR LIGHTING POWER ( ) EXTERIOR LIGHTING POWER (X) LIGHTING CONTROLS (X) EXIT SIGNS ( ) TANDEM WIRING ( ) ELECTRICAL MOTORS (X) MAINTENANCE INFORMATION ( ) PERMANENT CERTIFICATE

G.C. NOTE

APPLICABLE CODES N.Y.C. BUILDING CODE: 1968 N.Y.C. BUILDING CODE N.Y.C. PLUMBING CODE: 2014 INCLUDING LATEST UPDATES N.Y.C. MECHANICAL CODE: 2014 INCLUDING LATEST UPDATES N.Y.C. FUEL GAS CODE: 2014 INCLUDING LATEST UPDATES N.Y.C. ELECTRICAL CODE: N.E.C. 2011 INCLUDING LATEST UPDATES N.Y.C. FIRE CODE: 2014 N.Y.C. FIRE CODE ACCESSIBILITY: 2014 N.Y.C. BLDG. CODE, ANSI A117.1-2009 ED AND 2010 A.D.A. INCLUDING LATEST UPDATES NEW YORK STATE ENERGY CONSERVATION CODE; 2014 INCLUDING LATEST UPDATES. 1

04.28.17

ISSUED FOR BID

TWO HINGED DOORS IN SERIES

PROJECT 60" MIN 16" MIN

(a) BACK WALL

(b) SIDE WALL

GRAB BARS AT WATER CLOSETS

19" MAX

29 BROADWAY, 4TH FLOOR, NEW YORK, NY 10006

48" MIN

24" MAX

CLEAR FLOOR SPACE AT LAVATORIES

DEPTH

(b) CLEAR FLOOR SPACE

LAVATORY CLEARANCES

ADA WATER CLOSET CLEARANCES

CANCER RESEARCH INSTITUTE

NOT TO EXCEED FOUNTAIN DEPTH

48" MIN

CLEAR FLOOR SPACE

8" MIN 6" MAX KNEE 17" MIN TOE CLEARANCE CLEARANCE

(a) 36"x36" STALL

30" MIN

40" MAX

34" MAX

29" MIN

CLEAR FLOOR SPACE

9" MIN

27" MIN

LAV.

30" MIN

17" MIN

60" MIN FLOOR MTD. TOILET

42" MIN

19" MIN

TOP OF SEAT 17" - 19"

33" - 36"

12"

17"-19" MIN

18" MIN.

54" MIN

56" MIN WALL MTD TOILET

36" MIN 36" MIN 12" MIN 12" MIN

33" - 36"

48" MIN

TOILET PAPER DISPENSER 39"-41"

(d) BUILT-IN FOUNTAIN OR COOLER

SHEET TITLE

4TH FLOOR GENERAL NOTES

DRINKING FOUNTAINS AND WATER COOLERS

(b) T-SHAPED SPACE FOR 180Â° TURNS WHEELCHAIR TURNING SPACE

BACK

18"

01.17.2017 1505-16 KR

SEAT WALL

BACK

48" MAX.

SEAL & SIGNATURE 33"-36" 38" MAX.

36" MIN

CONTROL WALL

CONTROL AREA

18"

33"-36"

CONTROL WALL

SEAT WALL

48" MAX.

33"-36" SIDE

60" MIN (a) 30" x 60" STALL

33"-36" 38" MAX.

30" MIN

CONTROL AREA

12" MIN

18" MIN.

(a) 60 " DIAMETER SPACE

LAV.

18"

36" MIN

CONTROL WALL 36" MIN

60" MIN

60" MIN 60" MIN

36" MIN

12" MIN

60" MIN

HG AS NOTED

CONTROL WALL

42" MIN (a) 30" x 60" STALL

(a) 36"x36" STALL

(a) 36" X 36" STALL

A-001.00 1505-16GN04-A-001.00

000

DIVISION 1 - GENERAL REQUIREMENTS SITE & BUILDING GENERAL REQUIREMENTS A. CONTRACTOR SHALL MAINTAIN, FOR ENTIRE LENGTH OF HIS CONTRACT WORK, ALL EXIST. FIRE PROTECTIVE DEVICES TO CONFORM TO LOCAL BUILDING CODE REQUIREMENTS. B. CONTRACTOR SHALL TAKE ALL PRECAUTIONS TO MAINTAIN FIRE EGRESS THROUGH THE AREAS INVOLVED. PASSAGE AND EXIT STAIRS SHALL BE KEPT CLEAN AT ALL TIMES. C. CONTRACTOR SHALL MAKE ALL ARRANGEMENTS, MAINTAIN AND PAY ALL COSTS FOR TEMPORARY WATER AND PLUMBING, POWER AND LIGHTING AND HEATING OR VENTILATION AS HE MAY REQUIRE TO PROPERLY CONDUCT THE WORK OF HIS CONTRACT. CONTRACTOR SHALL BE RESPONSIBLE FOR ALL HOISTING RELATED TO THIS CONTRACT. ALL HOISTING CHARGES, IF ANY, SHALL BE INCLUDED AND COORDINATED WITH OWNER. D. DELIVERY BY COMMON CARRIER. THE CONTRACTOR SHALL HAVE A DULY AUTHORIZED REPRESENTATIVE PRESENT AT THE JOB-SITE TO BE RESPONSIBLE FOR RECEIVING ALL MATERIALS DELIVERED IN CONNECTION WITH THE WORK BY COMMON CARRIER. THE OWNER WILL HAVE NO RESPONSIBILITY FOR SUCH DELIVERIES AND WILL NOT ACCEPT THEM. E. REMOVALS, CLEAN-UP AND CONSTRUCTION PARTITIONING. E.1. CONTRACTOR SHALL PROTECT THE BUILDING PREMISES AND ALL OCCUPANTS ON THE PROJECT SITE. CONTRACTOR SHALL PROVIDE AND MAINTAIN ALL NECESSARY FLOOR AND WALL COVERING, BOARDS, TEMPORARY PARTITIONS AND DOORS AS REQUIRED TO PROTECT EXISTING WORK, FINISHES, FURNITURE AND FURNITURE SYSTEMS TO REMAIN AT THE JOB-SITE AND ALL AREAS OF BUILDING AFFECTED BY CONSTRUCTION. CONTRACTOR SHALL BE HELD RESPONSIBLE FOR ALL DAMAGES CAUSED BY IMPROPER PROTECTION AND SHALL MAKE ALL NECESSARY REPAIRS OR REPLACEMENTS WITHOUT ADDITIONAL CHARGE TO THE PARTY AFFECTED. E.2. CONTRACTOR SHALL BE RESPONSIBLE FOR MAINTAINING THE AREAS IN WHICH HE IS WORKING FREE FROM ACCUMULATION OF DEBRIS, BOXES, CRATES AND WASTE. ALL SUCH MATERIALS SHALL BE DISPOSED OF OFF SITE BY CONTRACTOR ON A DAILY BASIS AND COORDINATE WITH THE BUILDING MANAGER. CONTRACTOR SHALL BE RESPONSIBLE FOR REMOVAL OF DEBRIS FROM CARPET AND FURNITURE INSTALLATIONS. E.3. CONTRACTOR SHALL AT ALL TIMES KEEP THE PREMISES FREE OF ACCUMULATION OF WASTE MATERIALS AND RUBBISH; PREMISES TO BE SWEPT CLEAN DAILY. AT THE COMPLETION OF THE WORK, THE CONTRACTOR SHALL LEAVE THE JOB SITE FREE OF CONSTRUCTION DEBRIS AND MATERIALS, AND "BROOM CLEAN". JUST PRIOR TO TENANT OCCUPANCY, CONTRACTOR SHALL CLEAN ALL SURFACES OF DUST, DEBRIS, LOOSE CONSTRUCTION MATERIAL AND LEAVE ALL FLOORS VACUUMED CLEAN. REMAINING CONSTRUCTION MATERIAL AND EQUIPMENT, IF ANY, SHALL BE MOVED AND TEMPORARILY SECURED IN AN AREA DIRECTED BY OWNER. E.4. CONTRACTOR SHALL THOROUGHLY CLEAN OUT ALL DEBRIS WITHIN CONVECTORS OR ENCLOSURES BEFORE A FINISHED FLOOR IS INSTALLED. CONTRACTOR SHALL THOROUGHLY CLEAN ALL LIGHT FIXTURES AND FIXTURE LENSES; A/C DIFFUSERS AND REGISTERS; COVE BASE AND STRAIGHT BASE; ALL WALL COVERING INSTALLATIONS, AND DOORS; AND A/C CONVECTOR TOPS PRIOR TO LEAVING THE SITE. F.5. ALL WORK WHICH MIGHT AFFECT THE OPERATION OF THE EXISTING BUILDING SHALL BE PERFORMED AT THE CONVENIENCE OF THE OWNER . THE ARCHITECT AND OWNER SHALL BE NOTIFIED OF THIS WORK A MINIMUM OF THREE DAYS IN ADVANCE SO THAT THE PROPER ARRANGEMENTS MAY BE MADE. G. A COPY OF ALL PERMITS, PERFORATED DRAWINGS AND APPROVED APPLICATIONS FROM THE CITY OF NEW YORK DEPARTMENT OF BUILDINGS SHALL BE KEPT AT THE JOB SITE. THE CONSTRUCTION PERMITS MUST BE CONSPICUOUSLY POSTED AT THE JOB SITE. H. BURNING OF REMOVED MATERIALS IS NOT PERMITTED ON PROJECT SITE. I. CONTRACTOR SHALL BE RESPONSIBLE FOR ALL SAFETY CONDITIONS RELATING TO JOB CONSTRUCTION. J. CONTRACTOR SHALL RESPONSIBLE FOR SECURITY OF THE CONSTRUCTION AREA UNTIL IT IS TURNED OVER TO THE OWNER. K. CONTRACTOR SHALL BE RESPONSIBLE FOR ALL HOISTING RELATED TO THIS CONTRACT. L. NO ASBESTOS CONTAINING MATERIAL SHALL BE USED ON THIS PROJECT.

ADMINISTRATION & DOCUMENTATION GENERAL REQUIREMENTS A. CONTRACTOR SHALL VERIFY ALL CONSTRUCTION ADMINISTRATION RESPONSIBILITIES AND PROCEDURES WITH JANKO RASIC ARCHITECTS (JRA). B. CONTRACTOR SHALL NOTIFY JRA IMMEDIATELY IF IT CANNOT COMPLY WITH ALL NOTES CALLED FOR ON THIS SHEET AND ON ALL OTHER DRAWINGS. C. THE GC SHALL SUPPLY, PRIOR TO COMMENCING WORK, A LIST OF ALL TRADE CONTRACTORS TO JRA WITH NAME, ADDRESS AND PHONE NUMBER OF THE PRINCIPAL CONTACT OF EACH TRADE-CONTRACTOR. IN ADDITION, HE WILL FILE WITH THE BUILDING THE EMERGENCY NUMBERS AVAILABLE FOR 24-HR. CONTACT. D. THE CONTRACTOR AND HIS SUB-CONTRACTORS SHALL SUBMIT TO THE OWNER, PRIOR TO THE START OF CONSTRUCTION, CERTIFICATES OF INSURANCE WITH RESPECT TO WORKMAN'S COMPENSATION, PUBLIC LIABILITY AND PROPERTY DAMAGE. E. CONTRACTOR SHALL SUBMIT A CONSTRUCTION SEQUENCE AND SCHEDULE TO INCLUDE MATERIALS, DELIVERIES, AND WORK AFTER THE ACCEPTANCE OF THE BID AND PRIOR TO THE BEGINNING OF CONSTRUCTION FOR APPROVAL BY THE ARCHITECT. F. CONTRACTOR SHALL FURNISH JRA WITH BI-WEEKLY FIELD PROGRESS SCHEDULES FOR ALL PHASES OF CONSTRUCTION. G. ALL CORRESPONDENCE WITH CONSULTANT AND OWNER SHALL BE THROUGH THE ARCHITECT. H. OWNER, WITHOUT INVALIDATING THE CONTRACT, MAY ORDER EXTRA WORK WITH THE CONTRACT PRICE BEING ADJUSTED ACCORDINGLY. ALL SUCH WORK SHALL BE EXECUTED UNDER THE CONDITIONS OF THE ORIGINAL CONTRACT EXCEPT THAT ANY CLAIM FOR EXTENSIONS OF TIME CAUSED THEREBY SHALL BE ADJUSTED AT THE TIME OF ORDERING SUCH CHANGE. I. CONTRACTOR SHALL NOT PROCEED WITH ANY WORK FOR WHICH HE EXPECTS ADDITIONAL COMPENSATION BEYOND THE CONTRACT AMOUNT WITHOUT WRITTEN AUTHORIZATION FROM THE ARCHITECT AND OWNER.FAILURE TO OBTAIN SUCH AUTHORIZATION SHALL INVALIDATE ANY CLAIM FOR EXTRA COMPENSATION. J. CONTRACTOR SHALL NOTIFY THE ARCHITECT IN WRITING, AND RECEIVE APPROVAL, BEFORE ORDERING OR INSTALLING ITEMS OR MATERIALS WHICH ARE PROPOSED EQUALS. K. THE CONTRACT DOCUMENTS AND THE SCOPE OF WORK IS ILLUSTRATED BY THE DRAWINGS LISTED. ANY ADDITIONAL DETAIL DRAWINGS REQUIRED TO INTERPRET AND EXPLAIN THE DRAWINGS AND OTHER INFORMATION DEEMED NECESSARY BY JRA SHALL BE FURNISHED TO THE CONTRACTOR AS REQUIRED. THE ADDITIONAL DATA SHALL BE CONSIDERED TO FORM A PART OF THE CONTRACT AS THEY RELATE TO THE WORK. L. IF CONTRACTOR CLAIMS THAT ANY REVISIONS TO DOCUMENTS INVOLVE EXTRA COST UNDER THIS CONTRACT, HE SHALL GIVE OWNER AND JRA WRITTEN NOTICE THEREOF WITHIN A WEEK, OR REASONABLE TIME, AFTER THE RECEIPT OF SUCH INSTRUCTIONS, AND IN ANY EVENT BEFORE PROCEEDING TO EXECUTE THE WORK, AND THE PROCEDURE SHALL THEN BE AS PROVIDED FOR IN THE CHANGES OF WORK. NO SUCH CLAIM SHALL BE VALID UNLESS SO MADE. UNLESS OTHERWISE AGREED, NO PAYMENT ON SUCH BILLS WILL BE MADE UNTIL FINAL SETTLEMENT. M. ALL CLAIMS FOR EXTRA WORK WILL BE SUBMITTED IN WRITING FOR APPROVAL. N. RECORD DOCUMENTS CONTRACTOR SHALL MAINTAIN AT THE SITE FOR THE ARCHITECT, ONE COPY EACH OF: N.1. CURRENT DRAWINGS N.2. SPECIFICATIONS N.3. ADDENDA N.4. CHANGE ORDERS AND OTHER MODIFICATIONS TO THE CONTRACT N.5. ARCHITECT FIELD ORDERS, WRITTEN INSTRUCTIONS, SUPPLEMENTAL INSTRUCTIONS, APPROVED SKETCHES N.6. APPROVED SHOP DRAWINGS, PRODUCT DATAS AND SAMPLES N.7. FIELD TEST RECORDS O. CONTRACTOR SHALL MAINTAIN A CURRENT AND COMPLETE SET OF CONSTRUCTION DOCUMENTS ON THE CONSTRUCTION SITE DURING ALL PHASES OF CONSTRUCTION FOR USE BY ALL TRADES. P. RECORD DOCUMENTS: P.1. MAINTAIN DOCUMENTS IN A CLEAN, DRY, LEGIBLE CONDITION AND IN GOOD ORDER. DO NOT USE RECORD DOCUMENTS FOR CONSTRUCTION PURPOSES. P.2. MAKE DOCUMENTS AND SAMPLES AVAILABLE AT ALL TIME FOR INSPECTION BY ARCHITECT, OWNER, AND OWNER'S CONSULTANT. P.3. LABEL EACH DOCUMENT "PROJECT RECORD" IN NEAT LARGE-PRINTED LETTERS. P.4. RECORD INFORMATION CONCURRENTLY WITH CONSTRUCTION PROGRESS. DO NOT CONCEAL ANY WORK UNTIL REQUIRED INFORMATION IS RECORDED. LEGIBLY MARK DRAWINGS TO RECORD ACTUAL CONSTRUCTION.

DIVISION 1 - GENERAL REQUIREMENTS ADMINISTRATION & DOCUMENTATION cont'd Q. GUARANTEE. Q.1. ALL WORK AND MATERIALS INCLUDED IN THE CONTRACT DOCUMENTS SHALL BE UNCONDITIONALLY GUARANTEED AGAINST DEFECTS IN MATERIALS AND WORKMANSHIP FOR THE PERIOD STIPULATED IN THE MANUFACTURER'S SPECIFICATIONS OR FOR ONE YEAR, WHICHEVER IS LONGER. Q.2. THE GUARANTEE PERIOD SHALL BEGIN ON THE DATE THE OWNER ACCEPTS THE WORK BY WRITTEN NOTICE TO THE CONTRACTOR WITH A CERTIFICATE OF SUBSTANTIAL COMPLETION ISSUED BY THE ARCHITECT. Q.3. SHOULD ANY DEFECT OCCUR WITHIN THE ABOVE PERIOD, REPLACEMENT OR REPAIRS SHALL BE MADE PROMPTLY BY THE CONTRACTOR WITHOUT CHARGE TO THE OWNER. Q.4. NEITHER THE FINAL PAYMENT NOR ANY PROVISION IN THE CONTRACT DOCUMENTS SHALL CONSTITUTE AN ACCEPTANCE OF WORK NOT DONE IN ACCORDANCE WITH THE CONTRACT DOCUMENTS OR RELIEVE THE CONTRACTOR OF LIABILITY IN RESPECT TO ANY EXPRESS GUARANTEES OR RESPONSIBILITY FOR FAULTY MATERIALS OR WORKMANSHIP. Q.5. ALL GUARANTEES SHALL BE SIGNED BY THE CONTRACTOR AND SUBMITTED TO THE OWNER BEFORE FINAL PAYMENT. R. AT CONTRACT CLOSE-OUT, CONTRACTOR WILL DELIVER AT HIS COST, "AS-BUILT DRAWINGS" TO ARCHITECT. AS-BUILTS WILL REFLECT ALL CHANGES MADE DURING CONSTRUCTION AND NOTED ON RECORD DOCUMENTS. CONTRACTOR TO ALSO DELIVER ALL RECORD DOCUMENTS TO ARCHITECT. "AS BUILT DRAWINGS" SHALL CONSIST OF TWO (2) PRINTS OF EACH TRADE INCLUDING ALL SHOP DRAWINGS, CATALOGUE CUTS, ETC. AS PART OF THE CONTRACT. ONE (1) SET TO THE OWNER AND ONE (1) SET TO THE ARCHITECT. ALL AS-BUILT DRAWINGS TO BE DELIVERED IN HARDCOPY, ELECTRONIC PDF, AND CAD FORMATS. S. UPON COMPLETION OF WORK, ALL OF THE TRADE CONTRACTORS SHALL SUBMIT CERTIFICATES OF INSPECTION FROM LOCAL JURISDICTION(S) AS REQ'D. T. UPON COMPLETION OF WORK, CONTRACTOR SHALL NOTIFY JRA TO COMPILE A "PUNCHLIST" OF CORRECTIONS AND UNSATISFACTORY AND/OR INCOMPLETE WORK. FINAL PAYMENT WILL BE CONTINGENT UPON THE COMPLETION OF THESE ITEMS. GC TO SUBMIT SCHEDULE OF COMPLETION OF PUNCHLIST ITEMS. U. CONTRACTOR SHALL PROMPTLY CORRECT ALL WORK REJECTED BY JRA AS DEFECTIVE OR AS FAILING TO CONFORM TO THE CONTRACT WHETHER OBSERVED BEFORE OR AFTER COMPLETED. THE CONTRACTOR SHALL BEAR ALL COST FOR CORRECTING SUCH REJECTED WORK, INCLUDING THE COST OF JRA ADDITIONAL SERVICES THEREBY MADE NECESSARY.

ARCHITECT

DIVISION 1 - GENERAL REQUIREMENTS COORDINATION cont'd

DIVISION 6 - WOODWORK, PLASTIC, & COMPOSITES

DIVISION 8 - OPENINGS (DOORS & WINDOWS)

GENERAL NOTES FOR ALL WOODWORK, PLASTIC & COMPOSITES:

GENERAL NOTES FOR ALL OPENINGS:

GENERAL REQUIREMENTS AA. THERE SHALL BE NO SUBSTITUTION OF MATERIALS EXCEPT WHERE TERMS "EQUAL TO" OR "APPROVED" ARE USED. JRA SHALL DETERMINE EQUALITY BASED ON INFORMATION SUBMITTED BY THE CONTRACTOR. AB. CONTRACTOR SHALL SUBMIT FOR APPROVAL ALL SHOP DRAWINGS, SCHEDULES, SAMPLES AND SPECIFICATIONS CUTS FOR ALL SPECIFIED PRODUCTS. SHOP DRAWINGS SHALL BE DETAILED SHOWING THE FULL SCOPE OF DESIGN, CONSTRUCTION, REINFORCEMENT, AND DETAILS FOR APPROVAL BY JRA. A COPY OF ALL APPROVED SHOP DRAWINGS WITH THE JRA STAMP MUST BE KEPT AT THE JOB SITE AT ALL TIMES. GC SHALL SUBMIT FOR APPROVAL INCLUDING, BUT NOT LIMITED TO: DOORS, HARDWARE, GLASS, WINDOWS, APPLIANCES, MILLWORK, MISCELLANEOUS METALS, STAIRS, STAIR RAILINGS, LIGHT FIXTURES, PLUMBING FIXTURES, STONEWORK ETC. AC. ALL JRA APPROVALS OF SUBMITTALS SHALL BE FOR DESIGN INTENT ONLY. CONTRACTOR SHALL BE RESPONSIBLE FOR QUANTITIES, DIMENSIONS AND COMPLIANCE WITH CONTRACT DOCUMENTS AND FOR INFORMATION PERTAINING TO FABRICATION PROCESSES OR TECHNIQUES OF FIRST CLASS CONSTRUCTION AND FOR COORDINATION WITH OTHER TRADES. AD. DO NOT SCALE DRAWINGS; DIMENSIONS SHOWN GOVERN. LARGER SCALE DRAWINGS SHALL GOVERN OVER SMALLER SCALE. AE. THE CONTRACT DOCUMENTS AND THE SCOPE OF WORK IS ILLUSTRATED BY THE DRAWINGS LISTED. ANY ADDITIONAL DETAIL DRAWINGS REQUIRED TO INTERPRET AND EXPLAIN THE DRAWINGS AND OTHER INFORMATION DEEMED NECESSARY BY JRA SHALL BE FURNISHED TO THE CONTRACTOR AS REQUIRED. THESE ADDITIONAL DATA SHALL BE CONSIDERED TO FORM A PART OF THESE NOTES AS WORK, AF. CONTRACTOR SHALL BE RESPONSIBLE, AT HIS OWN COSTS, FOR WAREHOUSING OF ALL MATERIALS TO BE INSTALLED UNDER THIS

B. C.

E. F.

DIVISION 2 - SITE CONSTRUCTION NOT IN USE

DIVISION 3 - CONCRETE COORDINATION GENERAL REQUIREMENTS A. WORK LISTED ON THE PLANS, NOTES, AND SHOWN OR IMPLIED ON ALL DRAWINGS SHALL BE SUPPLIED AND INSTALLED BY THE TRADE CONTRACTOR. CONTRACTOR SHALL COORDINATE THE WORK OF ALL TRADES TO ASSURE THAT ALL CONTRACT CONDITIONS ARE MET. B. CONTRACTOR SHALL SUPERVISE AND DIRECT THE WORK USING HIS BEST SKILL AND ATTENTION. G.C. SHALL BE SOLELY RESPONSIBLE FOR ALL CONSTRUCTION MEANS, METHODS, TECHNIQUES, SEQUENCES AND PROCEDURES AND FOR COORDINATION OF ALL PORTION OF WORK. C. ALL WORK SHALL CONFORM TO ALL LOCAL CODES AND ORDINANCES,AND ALL OTHER AGENCIES HAVING JURISDICTION. D. CONTRACTOR SHALL COORDINATE HIS WORK WITH THE WORK OF ALL OTHER CONTRACTORS, WHETHER HIS OWN OR THOSE ON SEPARATE CONTRACT WITH THE OWNER. E. CONTRACTOR SHALL DO ALL CUTTING, FITTING AND PATCHING THAT MAY BE REQUESTED TO MAKE SEVERAL PARTS OF THE WORK COME TOGETHER PROPERLY AND TO FIT HIS WORK TO OTHER FIRMS AS SHOWN UPON OR REASONABLY IMPLIED BY THE DRAWINGS AND SPECIFICATIONS. THIS SHALL INCLUDE BUT NOT BE LIMITED TO PARTITIONING, DOORS, PIPINGS, DUCTWORKS, CONDUITS, ETC. F. CONTRACTOR SHALL BE RESPONSIBLE FOR CUTTING, PATCHING AND RESTORATION REQUIRED FOR THIS WORK. G. CONTRACTOR SHALL PATCH TO MATCH ADJACENT OR AS OTHERWISE DIRECTED BY ARCHITECT, ALL AREAS WHICH ARE AFFECTED BY THE DEMOLITION AND/OR NEW CONSTRUCTION AS DIRECTED BY ARCHITECT AND THE CONTRACT DRAWINGS. H. CONTRACTOR SHALL VERIFY FIELD CONDITIONS AT THE JOB-SITE PRIOR TO PRICE SUBMISSION. ANY DISCREPANCIES SHALL BE REPORTED TO THE ARCHITECT PRIOR TO THE PRICE PROPOSAL SUBMISSION, OTHERWISE, CONTRACTOR SHALL BEAR ALL COSTS TO COMPLETE THE WORK AS INTENDED ON DRAWINGS. I. CONTRACTOR SHALL VERIFY ALL DIMENSIONS AND CONDITIONS SHOWN ON DRAWINGS AND SHALL NOTIFY JRA OF ANY DISCREPANCIES, OMISSIONS, AND/OR CONFLICTS BEFORE PROCEEDING WITH THE WORK. J. mCONTRACTOR SHALL COORDINATE ALL OPENINGS SHOWN ON ARCHITECTURAL DRAWINGS WITH HVAC, ELECTRICAL, AND PLUMBING DRAWINGS K. CONTRACTOR SHALL VERIFY LOCATION OF EXISTING UTILITIES AND COORDINATE WITH LOCATION SHOWN ON DRAWINGS. L. ALL WORK SHALL BE PERFORMED BY SKILLED AND QUALIFIED WORKMEN IN ACCORDANCE WITH THE BEST PRACTICES OF THE TRADES INVOLVED AND IN COMPLIANCE WITH BUILDING REGULATIONS AND/OR GOVERNMENTAL LAWS, STATUTES OR ORDINANCES. M. CONTRACTOR SHALL BE RESPONSIBLE FOR THE PROMPT DISTRIBUTION OF DOCUMENTS TO ALL TRADES UNDER HIS JURISDICTION. N. CONTRACTOR SHALL PAY ALL COSTS ASSOCIATED WITH, AND SHALL COMPLY WITH, ALL REGULATIONS OF ALL AUTHORITIES REQUIRED TO SECURE ALL NECESSARY PERMITS, INSPECTIONS, TESTS AND APPROVAL FOR ALL TRADES. O. CONTRACTOR'S SUPERVISION - DURING THE ENTIRE PERIOD OF THE INSTALLATION OF THE WORK, CONTRACTOR SHALL BE REPRESENTED AT THE SITE OF THE WORK BY A QUALIFIED REPRESENTATIVE WHO SHALL BE EMPOWERED TO ACT ON HIS BEHALF, AUTHORIZED TO DISCUSS WORK AND RECEIVE DIRECTIONS FROM THE OWNER/ARCHITECT, SHALL BE PRESENT AT THE JOB SITE AT ALL TIMES THAT WORK IS IN PROGRESS, AND WHO SHALL BE RESPONSIBLE FOR: O.1. MANAGEMENT OF ALL ASPECTS OF THE WORK, INCLUDING A WEEKLY MEETING TO REVIEW THE PROGRESS. O.2. ESTABLISHMENT AND MAINTENANCE OF PROPER AND SAFE WORKING CONDITIONS WITH THE SITE OF THE WORK. O.3. TRANSMITTAL OF ALL INSTRUCTIONS ISSUED BY THE ARCHITECT. O.4. COMPLIANCE WITH ALL FEDERAL, STATE AND LOCAL LAWS. O.5. LAYING OUT AND COMPLETE COORDINATION OF ELEMENT OF WORK INCLUDING RESOLUTION OF PIPING, DUCTWORK, LIGHTS, CEILINGS, ETC. O.6. CHECKING OF ALL WORK IN PLACE FOR THE PURPOSE OF ASCERTAINING ITS COMPLIANCE WITH THE CONTRACT DOCUMENTS. O.7. REMOVAL AND PROPER REPLACEMENT OF ALL INSTALLED WORK WHICH IS NOT IN COMPLIANCE WITH THE CONTRACT DOCUMENTS. P. CONTRACTOR SHALL RETAIN THE SERVICES OF AN INDEPENDENT LICENSED PROFESSIONAL ENGINEER OR REGISTERED ARCHITECT TO EXECUTE THE REQUIRED SPECIAL INSPECTIONS AND FURNISH THE OWNER AND ARCHITECT WITH THE REPORTS. Q. PROVIDE ACCESS DOORS AS REQUIRED FOR PLUMBING, ELECTRICAL, HVAC, ETC. AS REQUIRED BY CODE. LOCATIONS TO BE APPROVED BY THE OWNER/ARCHITECT. R. ALL WELDING SHALL BE PERFORMED TO COMPLY WITH LOCAL, STATE, AND FEDERAL LAWS. ALL WELDING OPERATIONS PERFORMED UNDER THIS CONTRACT SHALL CONFORM TO THE STANDARDS AND SPECIFICATIONS STATED IN O.S.H.A. 29CFR1910.251, .252 AND SUBPART Q. S. CONTRACTOR SHALL BE RESPONSIBLE FOR ADEQUATELY BRACING AND PROTECTING ALL WORK DURING CONSTRUCTION AGAINST DAMAGE, BREAKAGE, COLLAPSE, DISTORTION AND MISALIGNMENT IN ACCORDANCE WITH APPLICABLE CODES, STANDARDS AND GOOD PRACTICE. T. ALL WORK SHALL BE ERECTED AND INSTALLED PLUMB, LEVEL, SQUARE, TRUE AND IN PROPER ALIGNMENT. U. ALL WORK SHALL BE ERECTED AND INSTALLED PLUMB, LEVEL, SQUARE, TRUE AND IN PROPER ALIGNMENT. V. ALL NEW FINISHES AND OTHER NEW MATERIAL INSTALLED BY THE TRADE CONTRACTOR IN ADDITION TO BEING AMPLY PROTECTED THROUGHOUT THE PERIOD OF CONSTRUCTION SHALL BE THOROUGHLY CLEANED TO THE SATISFACTION OF JRA JUST PRIOR TO BEING TURNED OVER TO THE OWNER. V.1. ALL DRAWINGS AND CONSTRUCTION NOTES ARE COMPLEMENTARY AND WHAT IS CALLED FOR BY ONE WILL BE AS BINDING AS IF CALLED FOR BY ALL. W. ALL MATERIALS SHALL BE NEW, UNUSED AND OF THE HIGHEST QUALITY IN EVERY RESPECT, UNLESS OTHERWISE NOTED. MANUFACTURED MATERIALS AND EQUIPMENT SHALL BE INSTALLED AS PER MANUFACTURER'S RECOMMENDATIONS AND INSTRUCTIONS. X. ALL MATERIALS SHALL BE NEW, UNUSED AND OF THE HIGHEST QUALITY IN EVERY RESPECT, UNLESS OTHERWISE NOTED. MANUFACTURED MATERIALS AND EQUIPMENT SHALL BE INSTALLED AS PER MANUFACTURER'S RECOMMENDATIONS AND INSTRUCTIONS. Y. THE USE OF THE WORDS "SUPPLIED BY" OR "PROVIDED" IN CONNECTION WITH ANY ITEM SPECIFIED IS INTENDED TO MEAN THAT SUCH ITEM SHALL BE FURNISHED, INSTALLED AND CONNECTED WHERE SO REQUIRED.

NOT IN USE

DIVISION 4 - MASONRY

NOT IN USE

DIVISION 5 - METALS GENERAL NOTES FOR ALL METALS: A.

F. G.

N. O. P.

T. U.

ALL MATERIALS, PRODUCTS, AND METHODS TO BE DELIVERED, HANDLED, AND INSTALLED PER MANUFACTURER'S SPECIFICATIONS, FREE OF DEFECT, AND SHALL COMPLY WITH APPLICABLE LOCAL LAWS AND BEST INDUSTRY PRACTICES AND WORKMANSHIP. DEFECTIVE PRODUCT/INSTALLATION SHALL BE REPLACED AT CONTRACTOR'S SOLE COST. ALL HARDWOOD PLYWOOD SHALL BE CONSTRUCTED ACCORDING TO COMMERCIAL STANDARD CS-35-36. WOOD AND ROUGH CARPENTRY SHALL BE GRADED BY AN AGENCY CERTIFIED BY THE NATIONAL FOREST PRODUCTS ASSOCIATION (NFPA) AND SHALL BE OF THE TYPE RECOMMENDED FOR THE APPLICATION INVOLVED. ALL EXPOSED AND SEMI-EXPOSED MILLWORK REQUIRED OR INDICATED ON THE DRAWINGS SHALL BE IN ACCORDANCE WITH THE CUSTOM GRADE OF THE ARCHITECTURAL WOODWORK INSTITUTE (AWI) AS TO WOOD SELECTION, JOINING, SIZING, FASTENING, AND FINISHING. WOOD TYPE AND/OR APPLIED FINISHES SHALL BE INDICATED ON THE DRAWINGS. ALL WOODWORK AND PLASTIC SHALL BE IN ACCORDANCE WITH AWI QUALITY STANDARDS SUBMITTALS (PRODUCT DATA): F.1.SUBMIT MANUFACTURER'S DATA SHEETS AND CATALOGUE CUTS FOR ALL PRODUCTS INCLUDING: BUFFING METHODS, SEALERS, FINISHES, STAINS, AND TREATMENTS FOR ARCHITECT'S APPROVAL. SUBMITTALS (SAMPLES): G.1. SUBMIT TWO 12"X12" (24"X48" FOR WOOD PANELING) SAMPLES OF EACH TYPE OF WOOD AND PLASTIC (INCLUDING CORIAN) WITH FINISH AND GLOSS AS SPECIFIED. G.2. FOR ALL REHABILITATION, RESTORATION, PRESERVATION, CLEANING, REFINISHING, AND BUFFING, PROVIDE SAMPLE AREA FOR ARCHITECT'S REVIEW AND APPROVAL. ARCHITECT TO DETERMINE LOCATION OF ON-SITE SAMPLE TEST AREA. G.3. SUBMIT THREE 6"x6" SAMPLES OF PLASTIC LAMINATES IN COLOR AND FINISH SPECIFIED. SUBMITTALS (DRAWINGS): H.1. SUBMIT SHOP DRAWINGS AT NO LESS THAN 3"=1'-0" SCALE FOR WOODWORK ITEMS AND BUILT-INS FOR ARCHITECT'S APPROVAL, SHOWING FIELD MEASUREMENTS, CONDITIONS, MATERIALS, JOINTS, AND HARDWARE, TYPICAL AND SPECIAL DETAILS OF CONSTRUCTION (INCLUDING WOOD GRAIN DIRECTION, SEAMING, REVEALS, JOINTS, FASTENERS). DRAWINGS ARE TO SHOW CLEARLY THE DESIGN, CONSTRUCTION, REINFORCEMENT, AND ALL FEATURES REQ'D TO FABRICATE THE ITEMS. DRAWINGS TO SHOW KEYED LOCATION WITHIN OVERALL PROJECT, PLANS, ELEVATIONS AND DETAILS OF EACH FABRICATION ALL HIGH-PRESSURE LAMINATED PLASTIC FACED PLYWOOD SURFACES (LAMINATE OR PLAM) FOR BOTH VERTICAL AND HORIZONTAL SURFACES SHALL BE PER AWI AND NEMA QUALITY STANDARDS. GLUE SHALL BE ACCORDING TO AWI, NEMA, AND REQUIREMENTS OF CS-35-36. ALL WOOD AND ROUGH CARPENTRY, INCLUDING BLOCKING, CLEATS AND FURRING, IS TO BE FIRE RETARDANT. PROVIDE PLASTIC LAMINATE WHERE NOTED OR INDICATED ON THE DRAWINGS. PLASTIC LAMINATE SURFACING TO BE HIGH PRESSURE PLASTIC LAMINATE, WHICH EQUALS OR EXCEEDS PERFORMANCE STANDARDS SET BY NATIONAL ELECTRICAL MANUFACTURER'S ASSOCIATION (NEMA-LD3, NEMA-GP-50) FOR CLASS 1 HIGH-PRESSURE DECORATIVE LAMINATES AS TO RESISTANCE, BURNS, STAINS, MOISTURE, WATER AND DIMENSIONAL CHANGE. COLOR AND FINISH QUALITY SHALL BE AS SELECTED BY ARCHITECT AND INDICATED ON DRAWINGS. LOW-PRESSURE LAMINATES (TFM-THERMOFUSED MELAMINE) SHALL NOT BE USED. BACKING TO BE HEAVY GAUGE AND IN ACCORDANCE WITH NEMA AND AWI STANDARDS. ALLOW AT LEAST 24 HOURS DRYING TIME PER COAT OF STAIN IN DUST-FREE ENVIRONMENT ALL WORK SHALL BE CAREFULLY CORNER BLOCKED, WELL-FITTED, GLUED AND REINFORCED WITH WOOD SCREWS. JOINT GLUE SHALL BE OF THE BEST QUALITY HIDE GLUE. ALL EXCESS GLUE MUST BE CLEANED FROM EXPOSED SURFACES. DRAWER FRONTS SHALL BE AS SPECIFIED. DRAWER SIDES TO BE OF SOLID OAK OR APPROVED EQUAL UON. DRAWER BOTTOMS SHALL BE MADE OF SOLID WOOD OR AS SPECIFIED. ALL DRAWERS SHALL HAVE SIDE OR BOTTOM GLIDES AS SPECIFIED AND TO BE LUBRICATED TO HAVE A SMOOTH, EFFORTLESS DRAWER ACTION. DRAWER BOTTOM TO BE REINFORCED. DRAWER INTERIORS, SHELVING, DRAWER SIDES, SUBFRONTS AND OTHER INTERIORS EXCEPT DRAWER BOTTOMS TO BE SOLID OAK AND SANDED SMOOTH, LACQUERED AND WAXED OR AS OTHERWISE SPECIFIED. ALL DRAWERS TO HAVE STOPS. DRAWERS TO BE FULL EXTENSION UON. ALL FINISHES TO BE SMOOTH, ALCOHOL RESISTANT, AND STAIN RESISTANT AND ARE TO BE MOISTURE AND WATER REPELLANT UON. ALL LIGHTING INTEGRATED WITH ARCHITECTURAL WOODWORK MUST BE UL APPROVED FOR WET LOCATIONS OR DRY AS REQUIRED. ALL MILLWORK SHALL BE SHOP ASSEMBLED. WORK THAT IS TOO LARGE FOR ENTRANCE INTO THE USE AREA SHALL BE FABRICATED IN DETACHABLE SECTIONS WITH PROVISIONS FOR RECONNECTION THE SECTIONS IN THEIR FINAL POSITION THAT WILL NOT BE VISIBLE UPON COMPLETION OF THE INSTALLATION. CONTRACTOR IS RESPONSIBLE FOR VERIFICATION OF MAXIMUM DELIVERABLE SIZE OF ALL UNITS ONTO THE PROJECT PREMISES AND TO THE POINT OF INSTALLATION. CONTRACTOR TO FURNISH ALL LABOR AND MATERIALS TO COMPLETE ALL WORK SHOWN ON THE DRAWINGS INCLUDING BUT NOT LIMITED TO FASTENINGS, BRACES, CONNECTIONS, ATTACHMENTS, AND ADHESIVES AS RECOMMENDED BY MFR. FABRICATE ITEMS OF THE MATERIAL, SIZE AND DIMENSIONS INDICATED. PRE-ASSEMBLE AND APPLY FINISHES IN SHOP TO GREATEST EXTENT POSSIBLE USING CONCEALED FASTENERS AND SECURE IN-PLACE, ON-SITE AS REQ'D. DO NOT CUT OR ABRADE FINISHES WHICH CANNOT BE COMPLETELY RESTORED IN FIELD. RETURN SUCH ITEMS TO THE SHOP FOR REQUIRED ALTERATIONS AND COMPLETE REFINISHING. AT COMPLETION OF THE PROJECT, REMOVE ALL PROTECTIVE COVERINGS AND CLEAN EXPOSED SURFACES. ALL WORK AND MATERIALS (INCLUDING INSTALLATION, MATERIAL & WORKMANSHIP WARRANTY) INCLUDED IN THE CONTRACT DOCUMENTS SHALL BE UNCONDITIONALLY GUARANTEED AGAINST DEFECTS IN MATERIALS AND WORKMANSHIP FOR THE PERIOD STIPULATED IN THE MANUFACTURER'S SPECIFICATIONS OR FOR ONE YEAR, WHICHEVER IS LONGER.

DIVISION 7 - THERMAL & MOISTURE PROTECTION GENERAL NOTES FOR ALL THERMAL & MOISTURE PROTECTION: A.

D. E.

F. G.

DOORS AND FRAMES

MEP ENGINEER:

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

EXPEDITER:

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

CLIENT:

IN ADDITION TO DIVISION 8 GENERAL NOTES FOR OPENINGS: H. DOORS AND FRAMES SPECIFICATION REQUIREMENTS: H.1. INDICATE MODEL#, MATERIAL, AND FINISH ON SAMPLE SUBMITTALS. H.2. SUBMIT SHOP DRAWINGS SHOWING ELEVATIONS, DETAILS, JOINTS, JUNCTIONS/CONNECTIONS, END CONDITIONS, FIELD MEASUREMENTS AND CONDITIONS, TYPICAL AND SPECIAL DETAILS OF CONSTRUCTION (INCLUDING BUT NOT LIMITED TO JAMB DETAILS, HEADER DETAILS, THRESHOLD DETAILS, AND HARDWARE. SHOP DRAWINGS TO BE NO LESS THAN 3” = 1'-0” SCALE FOR DETAILS. H.3. INCLUDE INFORMATION FOR DOORS/FRAMES ON STANDARD PROJECT HARDWARE AND DOOR SCHEDULES. SUBMIT HARDWARE & MATERIAL SCHEDULES FOR ARCHITECT'S REVIEW AND APPROVAL. INCLUDING BUT NOT LIMITED TO HANDLES, FLUSH BOLTS, ACOUSTIC SEALS, LOCKS, HINGES, CONCEALED SLIDE TRACKS, DOORS.

HARDWARE IN ADDITION TO DIVISION 8 GENERAL NOTES FOR OPENINGS: A. CYLINDER LOCKS SHALL BE INDIVIDUALLY KEYED AND MASTERKEYED FOR CLIENT'S USE. CONTRACTOR SHALL COORDINATE WITH THE CLIENT AND LANDLORD FOR KEYING SCHEDULE AND ADDITIONAL REQUIREMENTS OF THE BUILDING PRIOR TO PURCHASING OF HARDWARE. CONTRACTOR SHALL PROVIDE KEYS AS REQUESTED BY THE CLIENT. B. ALL DOORS SHALL HAVE DOME-TYPE DOOR STOPS WITH RUBBER BUMPERS AND DOOR SILENCERS, UON C. HARDWARE FINISH OF ALL EXPOSED HARDWARE SHALL BE COORDINATED TO MATCH. REFER TO HARDWARE SCHEDULE ON DRAWINGS FOR HARDWARE TYPE. D. GC TO SUBMIT HARDWARE SCHEDULE INCLUDING LOCKSET MODEL AND FUNCTION, CLOSER TYPE, HINGE, DOOR STOP, ETC. FOR EACH HARDWARE SET AND SUBMIT FOR ARCHITECT'S REVIEW.

GLAZING IN ADDITION TO DIVISION 8 GENERAL NOTES FOR OPENINGS: E. INSTALLATION SHALL BE IN ACCORDANCE WITH FLAT GLASS MARKETING ASSOCIATION (FGMA) GLAZING MANUAL. F. ALL GLASS SHALL BE CLEAR SAFETY GLASS (UON), EITHER TEMPERED OR LAMINATED, THICKNESS AS INDICATED ON DRAWINGS OR AS RECOMMENDED BY MANUFACTURER. ALL EXPOSED EDGES TO BE POLISHED G. MIRRORS SHALL BE ONE PIECE, FRAMELESS, UON, AND GUARANTEED AGAINST SILVER OXIDATION. H. ADDITIONAL GLAZING SUBMITTAL REQUIREMENTS: H.A. SAMPLES: THREE 6"x6" SAMPLES OF EACH GLASS AND MIRROR TYPE SPECIFIED. H.B. DRAWINGS: SUBMIT GLAZING SHOP DRAWINGS FOR ALL GLASS (FIXED OR OPERABLE) AND MIRRORS. ELEVATIONS AND DETAILS OF ALL CONDITIONS AND FASTENING TECHNIQUES TO BE DRAWN AT A SCALE OF 3"=1'-0" I. ALL ITEMS SHALL BE WRAPPED AND PACKAGED TO ENSURE THAT BREAKAGE IS INHIBITED DURING SHIPPING. J. SILICONE, OR OTHERWISE NOTED SEALANT OR GASKET, IS REQ'D AT ALL FIXED CONNECTIONS (INCLUDING BUT NOT LIMITED TO DOOR FRAME TO WALL, MILLWORK TO WALL, DISSIMILAR MATERIALS, AT OPENINGS OR PENETRATIONS THROUGH WALLS, AND ALL GLASS TO GLASS TRANSITIONS) STRUCTURAL SILICONE MAY BE REQ'D AT PARTIAL FREESTANDING GLASS AREAS, AND GC SHALL PROVIDE AS REQ'D. K. CONTRACTOR IS RESPONSIBLE FOR SUPPLYING ALL HARDWARE AT STANDARD AND CUSTOM GLASS SHOWER DOORS. L. INSTALL DOORS, WINDOWS, AND FRAMES PLUMB AND SQUARE. RIGIDLY ANCHOR FRAMES TO ADJACENT CONSTRUCTION. M. CONTRACTOR MUST VERIFY ALL OPENINGS, THROAT DIMENSIONS, AND FIELD CONDITIONS AND NOTIFY JRA OF DISCREPANCIES PRIOR TO ORDER

04.28.17

ISSUED FOR BID

PROJECT

CANCER RESEARCH INSTITUTE 29 BROADWAY, 4TH FLOOR, NEW YORK, NY 10006 SHEET TITLE

4TH FLOOR GENERAL NOTES 01.17.2017 1505-16 KR

SEAL & SIGNATURE

HG AS NOTED

A-002.00 1505-16GN04-A-002.00

000

ARCHITECT

DIVISION 9 - FINISHES

DIVISION 9 - FINISHES cont'd

DIVISION 12 - FURNISHING

GENERAL NOTES FOR ALL FINISHES:

09.70.00 WALL FINISHES (INCLUDES ALL SUBDIVISIONS)

GENERAL NOTES FOR ALL SPECIALTIES:

A. ALL MATERIALS, PRODUCTS, AND METHODS TO BE DELIVERED, HANDLED, AND INSTALLED PER MANUFACTURER'S SPECIFICATIONS, FREE OF DEFECT, AND SHALL COMPLY WITH APPLICABLE LOCAL LAWS AND BEST INDUSTRY PRACTICES AND WORKMANSHIP. DEFECTIVE PRODUCT/INSTALLATION SHALL BE REPLACED AT CONTRACTOR'S SOLE COST. B. SUBMITTALS (PRODUCT DATA): B.1. PRODUCT DATA: SUBMIT MANUFACTURER'S DATA SHEETS AND CATALOGUE CUTS FOR ALL ITEMS INCLUDING BUT NOT LIMITED TO TILE, MORTAR, GROUT, ADHESIVES C. SUBMITTALS (SAMPLES): C.1. SUBMIT TWO 12"X12" (WOOD PANELS FOR FLOOR, CEILING, WALLS TO BE 24"X48") SAMPLES OF EACH TYPE OF SPECIFIED FINISH INCLUDING GWB, CEILING, SUSPENSION SYSTEMS, FLOORING (INCLUDING WOOD, STONE, COMPOSITION STONE, MASONRY, WOOD, RESILIENT, FLUID-APPLIED, TERRAZZO, CARPETING), WALL FINISHES (INCLUDING STONE FACING AND ACOUSTIC FINISHES), PAINTS AND COATINGS, STAINS, SEALANTS, BUFFING, SUPPORTS, ADHESIVES, MUDSET, SUBSTRATES, AND GROUTS FOR JRA'S APPROVAL. FINISH SHALL MATCH JRA'S APPROVED SAMPLE. IF 12"X12" SAMPLE CANNOT BE PROVIDED, PROVIDE IN-FIELD SAMPLE AREA FOR ARCHITECT'S REVIEW AND APPROVAL. ARCHITECT TO DETERMINE LOCATION OF SAMPLE TEST AREA. D. SUBMITTALS (DRAWINGS): D.1. SUBMIT SHOP DRAWINGS AT NO LESS THAN 3"=1'-0" FOR TILING, CEILING, FLOORING, AND WALL FINISH DETAILS SHOWING LAYOUT, SEAMS, FIELD MEASUREMENTS, CONDITIONS, START TILE(S), PATTERNS, COLOR ARRANGEMENT, COURSING, ALIGNMENTS, MATERIAL DIRECTION, PERIMETER CONDITIONS, WATERPROOF MEMBRANES (SHOW FULL EXTENTS IN PLAN AND IN DETAIL DRAWINGS), JOINTS (INCLUDING CONTROL AND EXPANSION), HARDWARE, SUPPORTS, ADHESIVES, SETTING BEDS, JUNCTIONS WITH DISSIMILAR MATERIALS, THRESHOLDS AND SETTING DETAILS, TYPICAL AND SPECIAL DETAILS OF CONSTRUCTION (INCLUDING FLOORING/CEILING/WALL FINISH MATERIAL PATTERNS, DIRECTION, COLOR ARRANGEMENT, SEAMING, START TILE(S) OR PANEL(S), REVEALS, JOINTS, FASTENERS, TRANSITIONS/JUNCTIONS TO DISSIMILAR MATERIALS, THRESHOLDS, PERIMETER CONDITIONS, AND SETTING DETAILS). DRAWINGS ARE TO SHOW CLEARLY THE DESIGN, CONSTRUCTION, REINFORCEMENT, AND ALL FEATURES REQ'D TO FABRICATE THE ITEMS. DRAWINGS TO SHOW PLANS, ELEVATIONS, AND DETAILS. E. CONTRACTOR TO FURNISH ALL LABOR AND MATERIALS TO COMPLETE ALL WORK SHOWN ON THE DRAWINGS INCLUDING BUT NOT LIMITED TO FASTENINGS, BRACES, CONNECTIONS, ATTACHMENTS, MORTAR, GROUT, SEALANTS, BUFFING, CAPS, STOPS, BASES, RETURNS, TRIMMERS, THRESHOLDS, AND OTHER SHAPES TO COMPLETE INSTALLATION AND ADHESIVES AS RECOMMENDED BY MFR. F. FABRICATE ITEMS OF THE MATERIAL, SIZE AND DIMENSIONS INDICATED. PRE-ASSEMBLE IN SHOP TO GREATEST EXTENT POSSIBLE USING CONCEALED FASTENERS AND SECURE IN-PLACE, ON-SITE AS REQ'D. G. DO NOT CUT OR ABRADE FINISHES WHICH CANNOT BE COMPLETELY RESTORED IN FIELD. RETURN SUCH ITEMS TO THE SHOP FOR REQUIRED ALTERATIONS AND COMPLETE REFINISHING. H. AT COMPLETION OF THE PROJECT, REMOVE ALL PROTECTIVE COVERINGS AND CLEAN EXPOSED SURFACES. I. ALL WORK AND MATERIALS (INCLUDING INSTALLATION, MATERIAL & WORKMANSHIP WARRANTY) INCLUDED IN THE CONTRACT DOCUMENTS SHALL BE UNCONDITIONALLY GUARANTEED AGAINST DEFECTS IN MATERIALS AND WORKMANSHIP FOR THE PERIOD STIPULATED IN THE MANUFACTURER'S SPECIFICATIONS OR FOR ONE YEAR, WHICHEVER IS LONGER.

09.20.00 PLASTER AND GYPSUM BOARD IN ADDITION TO DIVISION 9 GENERAL NOTES FOR ALL FINISHES: A. DRYWALL MATERIALS SHALL COMPLY WITH ANSI SPECIFICATIONS FOR THE APPLICATION AND FINISHING OF WALLBOARD, ANSI A97.1. CONTRACTOR SHALL BE RESPONSIBLE FOR USING COMPATIBLE PRODUCTS FOR COMPLETE CONSTRUCTION ASSEMBLY. B. SUBMIT TWO SAMPLES OF EACH TYPE OF PLASTER MOUNTED ON HARDWOOD PANELS. C. MATERIALS SHALL BE BY UNITED STATES GYPSUM OR APPROVED EQUAL. D. METAL STUDS SHALL BE 2-1/2", 25 GAUGE MINIMUM. UON. FRAMING SHALL BE SECURELY ANCHORED, TOP AND BOTTOM, AND SHALL BE SPACED 16" O.C. MAXIMUM ON STRAIGHT DRYWALL PARTITIONS UON. IN FIRE RATED PARTITIONS, STUDS SHALL BE 16" O.C. GYPSUM WALLBOARD SHALL BE 5/8" THICK, FIRE RATED AND APPLIED VERTICALLY WITH SCREW FASTENERS UON. PROVIDE TAPING AND SPACKLING WITH COMPATIBLE MATERIAL. PARTITIONS SHALL BE BRACED OR SECURED SUFFICIENTLY FROM DEFLECTION OF 1/4" PER 8'-0" LENGTH IN ANY DIRECTION. PROVIDE BRACING OF PARTITIONING WORK WHERE REQUIRED TO DIMINISH DEFLECTION PROBLEMS. E. SOUND INSULATED AND FIRE-RATED PARTITIONING SHALL BE CAULKED AT PERIMETERS AND PROVIDED WITH BUILDING STANDARD FIRE-RATED AND SOUND ATTENUATING INSULATION SECURELY FASTENED TO STUD FRAMING. AT THESE PARTITIONS, BACK TO BACK JUNCTION BOXES ARE NOT PERMITTED. FILL ALL GAPS INCLUDING THOSE INSIDE/BEHIND PERIMETER COVER. F. JRA SHALL APPROVE CHALKED PARTITION LAYOUT PRIOR TO CONSTRUCTION COMMENCEMENT. CONTRACTOR SHALL NOTIFY ARCHITECT THREE (3) DAYS PRIOR TO COMPLETION OF LAYOUT FOR APPROVAL. G. ALL DRYWALL PARTITIONING SHALL BE PLUMB, LEVEL, TRUE AND STRAIGHT, PROPERLY BRACED AND RIGID. SURFACES SHALL BE SMOOTH AND FREE FROM FLAWS AND DEFECTS IN A READY TO FINISH CONDITION. ALL TAPING AND SPACKLING SHALL BE SANDED, SPONGED DOWN, AND PREPARED SO THAT LOCATION OF JOINTS AND BLEMISHES CAN NOT BE DETECTED AFTER WALL HAS BEEN FINISHED. H. TOLERANCE: PLUS OR MINUS 1/4" FROM DIMENSIONS INDICATED ON DRAWINGS. IT IS BROUGHT TO THE CONTRACTOR'S ATTENTION THAT THESE TOLERANCES WILL BE STRICTLY ENFORCED. I. DELIVER, STORE AND HANDLE PRODUCTS WITH MAXIMUM CARE TO PREVENT ANY DAMAGE OR WARPAGE. FIRE-RATED MATERIALS MUST BEAR TESTING AGENCY LABELS AND REQUIRED FIRE CLASSIFICATION NUMBERS.

09.22.00 SUPPORTS FOR PLASTER AND GYPSUM BOARD IN ADDITION TO DIVISION 9 GENERAL NOTES FOR ALL FINISHES: A. SUSPENDED CEILINGS SHALL COMPLY WITH PARAGRAPH 27-350 AND RS 5-16 OF THE NEW YORK CITY BUILDING CODE, LATEST EDITION. B. MAIN SUSPENSION SYSTEM SHALL CONSIST OF MIN. 5/16"FLAT IRON HANGERS 4'-6" O.C. MAX EXPANSION BOLTED TO THE SLAB ABOVE. 1-1/2" COLD ROLLED CHANNELS SHALL BE CONNECTED TO THE HANGERS AT 4'-0" O.C. MAX BY MEANS OF APPROVED CLIPS. THE CEILING SUSPENSION SYSTEMS SHALL BE SUPPORTED DIRECTLY FROM THE CHANNELS. C. GYPSUM CEILINGS: C.1. ATTACH HAT-SHAPED METAL FURRING CHANNELS TO THE COLD-ROLLED CHANNELS BY MEANS OF METAL FURRING CHANNEL CLIPS AT 16" O.C. MAX. C.2. ATTACH 5/8" GYPSUM BOARD UON TO THE FURRING CHANNELS AS RECOMMENDED BY THE GYPSUM BOARD MFR.

09.30.00 FLOORING IN ADDITION TO DIVISION 9 GENERAL NOTES FOR ALL FINISHES: A. SAMPLE SUBMITTALS: SUBMIT TWO 12"X12" SAMPLES OF EACH TYPE OF SPECIFIED MATERIAL AT SPECIFIED THICKNESS AND FINISH. FOR FINISHES SMALLER THAN 4" IN ANY ONE DIMENSION, SAMPLES SHALL BE MOUNTED ON HARDWOOD PANELS AND GROUTED. FOR ALL STONE, MFR/CONTRACTOR TO PROVIDE CURRENT QUARRY RANGE OF AT LEAST 3 SAMPLES EACH 12"x12" IN SIZE. B. REPLACE DAMAGED OR STAINED TILES PRIOR TO SUBSTANTIAL COMPLETION. C. PROVIDE WATERPROOF SHEET MEMBRANE AT ALL BATHROOMS, KITCHENS, AND OTHER WET AREAS D. WHERE REQ'D PROVIDE A CLEAVAGE MEMBRANE OF 15 LB ASPHALT SATURATED FELT, UNPERFORATED E. SEALANT AS PER MFR'S SPECIFICATIONS WITH CLEAR STONE SEALER FINISH, IMPREGNATOR, OR APPROVED EQUAL TO RESIST WATER, ALCOHOL, AND CHEMICAL STAINS. F. GC TO BLEND TILES FOR NATURAL COLOR VARIATION. JRA TO APPROVE LAYOUT PRIOR TO GROUTING. G. LEVEL AND PATCH FLOOR AND WALL SURFACES PRIOR TO INSTALLATION H. GROUT WIDTH AS RECOMMENDED BY MFR AND APPROVED BY ARCHITECT I. GC TO PROVIDE ATTIC STOCK OF ALL TILES AND STONEWORK EQUIVALENT TO 10% OF TOTAL INSTALLED AREA AT HIS SOLE COST J. AT COMPLETION OF THE PROJECT CLEAN EXPOSED SURFACES, BUFF, AND SEAL PER MFR'S RECOMMENDATION

09.90.00 PAINTING AND COATING

IN ADDITION TO DIVISION 9 GENERAL NOTES FOR ALL FINISHES: A. CONTRACTOR SHALL INSPECT ALL SURFACES AND PROVIDE ALL PREPARATORY WORK NECESSARY IN ORDER TO RECEIVE NEW FINISH, INCLUDING PROPER SCRAPING AND PREPARATION, ESPECIALLY ON METAL SURFACES (ELEVATOR DOORS, CONVECTORS, ETC.). B. 09.91.00 FOR PAINTING: B.1. PROVIDE 1 (ONE) COAT PRIMER AND 2 (TWO) COATS PAINT B.2. ALL PAINTING MATERIALS SHALL BE USED ONLY IN STRICT CONFORMANCE WITH THE MFR'S LATEST PRINTED SPECIFICATIONS AND INSTRUCTIONS. B.3. PAINT SHALL BE APPLIED BY SKILLED TRADESMAN AND SHALL BE FREE OF ALL RUNS, BRUSH MARKS, SAGS, HOLIDAYS AND OTHER DEFECTS. B.4. ALL WOOD SURFACES, SPECIFIED TO BE PAINTED, ARE TO BE PAINTED WITH OIL-BASED PAINT (COLOR AND FINISH SELECTED BY ARCHITECT) B.5. CONTRACTOR SHALL REMOVE AND PATCH HOLES FROM MISC. NAILS, HOOKS, STAPLES, WIRES AND OTHER SURFACE ITEMS THAT ARE NOT REQ'D PARTS OF EXIST. OR NEW INSTALLATIONS PRIOR TO PERFORMING ANY GENERAL SURFACE PREPARATIONS. B.6. UPON COMPLETION OF PAINTING WORK, CLEAN AND TRIM ALL WINDOW GLASS WITH A RAZOR BLADE AND CLEAN OTHER PAINT SPLATTERED SURFACES (INCLUDING LIGHT FIXTURES) USING DILIGENT CARE NOT TO SCRATCH OR OTHERWISE DAMAGE FINISHED SURFACES. B.7. PREPARATION AND CLEANING PROCEDURES TO BE IN STRICT CONFORMANCE WITH MFR'S INSTRUCTION AND AS HEREIN SPECIFIED FOR EACH PARTICULAR SUBSTRATE CONDITION. REMOVE ALL ELECTRICAL DEVICE COVER PLATES, SURFACE HARDWARE, SURFACE MOUNTED DEVICES, AND SIMILAR OBSTRUCTIONS PRIOR TO PAINTING. REPLACE SAME UPON COMPLETION OF WORK. MASK DOOR HARDWARE AND OTHER ITEMS WHICH CAN NOT PRACTICALLY BE REMOVED. FILL AND SKIM COAT OVER HOLES, CRACKS, SURFACE INDENTATIONS AND IRREGULARITIES WITH PATCHING COMPOUNDS COMPATIBLE WITH SUBSTRATE APPROPRIATE FOR THE SURFACE TEXTURE REQUIRED AND PATCH AND SAND TO A LEVEL SURFACE AND PROPERLY PREPARE FOR SPECIFIED FINISHES ALL SURFACES SHOWN TO RECEIVE NEW FINISHES. SHELLAC AND SEAL MARKS WHICH MAY BLEED THROUGH FINISH. FOR METAL SURFACES, REMOVE DIRT AND GREASE WITH MINERAL SPIRITS. REMOVE RUST AND CHIPPED PAINT DOWN TO A SOUND SURFACE AND APPLY RUST PROOF PRIMER. SAND EXISTING GLOSSY SURFACES PRIOR TO PAINTING. WIPE SANDED SURFACES WITH DE-GLOSSING SOLUTION TO ACHIEVE A FULLY DE-GLOSSED SUBSTRATE. FILL SPACES AROUND DOOR FRAMES, CABINETRY, BUILT-INS, AND ALL OTHER JOINTS BETWEEN DISSIMILAR MATERIALS WITH PAINTABLE CAULK. B.8. PAINT IS NOT TO BE APPLIED WHILE ANY ACTIVITIES CAUSING DUST (SANDING, CUTTING, DRILLING) ARE OCCURRING IN THE IMMEDIATE OR ADJACENT AREA. C. 09.93.00 FOR STAINING AND TRANSPARENT FINISHING: C.1. ALL FINISHES SHALL BE PER MFR'S SPECIFICATION. SAND AND PREP SURFACE AS REQ'D. PRIOR TO PRODUCT APPLICATION. PRODUCT SHALL BE FREE OF ALL RUNS, BRUSH MARKS, BLOTCHES, AND OTHER DEFECTS. TO FULLEST EXTENT POSSIBLE, COMPLETE WORK OFF-SITE AND TRANSPORT TO SITE. D. 09.94.00 THROUGH 09.97.00 SPECIAL FINISHES AND COATINGS: E. IF 12"X12" SAMPLE CANNOT BE PROVIDED, PROVIDE IN-FIELD SAMPLE AREA FOR ARCHITECT'S REVIEW AND APPROVAL. ARCHITECT TO DETERMINE LOCATION OF SAMPLE TEST AREA. F. FOR ALL ITEMS (INCLUDING BUT NOT LIMITED TO INTUMESCENT PAINT, EPOXY COATINGS, FIRE-RETARDANT COATINGS, METAL/MASONRY/CONCRETE FINISHES ETC.): CONTRACTOR TO PROVIDE ALL BASE (PRIMER) AND FINISH COATS PER MFR'S SPECIFICATION. G. ALL WORK MUST BE DONE BY SKILLED, MFR-APPROVED INSTALLERS. ALL WORK AND MATERIALS TO BE OF THE HIGHEST INDUSTRY STANDARD.

DIVISION 10 - SPECIALTIES GENERAL NOTES FOR ALL SPECIALTIES: A. ALL MATERIALS, PRODUCTS, AND METHODS TO BE DELIVERED, HANDLED, AND INSTALLED PER MFR'S SPECIFICATIONS, FREE OF DEFECT, AND SHALL COMPLY WITH APPLICABLE LOCAL LAWS AND BEST INDUSTRY PRACTICES AND WORKMANSHIP. DEFECTIVE PRODUCT & INSTALLATION SHALL BE REPLACED AT CONTRACTOR'S SOLE COST B. SUBMITTALS (PRODUCT DATA): B.1. SUBMIT MFR'S DATA SHEETS AND CATALOGUE CUTS FOR ALL ITEMS INCLUDING BUT NOT LIMITED TO FASTENERS AND HARDWARE, CONTROLS/ELECTRIC DEVICES, AND OPERATING EQUIPMENT. C. SUBMITTALS (SAMPLES): C.1. SUBMIT TWO SAMPLES OF EACH FINISH AND HARDWARE D. SUBMITTALS (DRAWINGS): D.1. SUBMIT SHOP DRAWINGS SHOWING PLANS; ELEVATIONS; SECTIONS; DETAILS; CONDITIONS AT OPENINGS WITH VARIOUS WALL THICKNESS AND MATERIALS; FIELD MEASUREMENTS; DOOR SWING DIRECTIONS; LOCKS; OPERABLE MECHANISMS AND CONTROLS; TYPICAL AND SPECIAL DETAILS OF CONSTRUCTION; METHODS OF ASSEMBLING SECTIONS; JOINTS AND CONNECTIONS. SUBMIT WIRING DIAGRAMS E. CONTRACTOR TO FURNISH ALL LABOR AND MATERIALS TO COMPLETE ALL WORK SHOWN ON THE DRAWINGS INCLUDING BUT NOT LIMITED TO HARDWARE, FASTENINGS, SUPPORTS, CONNECTIONS, ATTACHMENTS, BLOCKING, AND ADHESIVES AS RECOMMENDED BY MFR. F. FABRICATE ITEMS OF THE MATERIAL, SIZE AND DIMENSIONS INDICATED. PRE-ASSEMBLE IN SHOP TO GREATEST EXTENT POSSIBLE USING CONCEALED FASTENERS AND SECURE IN-PLACE, ON-SITE AS REQ'D. G. DO NOT CUT OR ABRADE FINISHES WHICH CANNOT BE COMPLETELY RESTORED IN FIELD. RETURN SUCH ITEMS TO THE SHOP FOR REQUIRED ALTERATIONS AND COMPLETE REFINISHING. H. AT COMPLETION OF THE PROJECT, REMOVE ALL PROTECTIVE COVERINGS AND CLEAN EXPOSED SURFACES. I. ALL WORK AND MATERIALS (INCLUDING INSTALLATION, MATERIAL & WORKMANSHIP WARRANTY) INCLUDED IN THE CONTRACT DOCUMENTS SHALL BE UNCONDITIONALLY GUARANTEED AGAINST DEFECTS IN MATERIALS AND WORKMANSHIP FOR THE PERIOD STIPULATED IN THE MFR'S SPECIFICATIONS OR FOR ONE YEAR, WHICHEVER IS LONGER.

DIVISION 11 - EQUIPMENT NOT IN USE

ALL MATERIALS, PRODUCTS, AND METHODS TO BE DELIVERED, HANDLED, AND INSTALLED PER MFR'S SPECIFICATIONS, FREE OF DEFECT, AND SHALL COMPLY WITH APPLICABLE LOCAL LAWS AND BEST INDUSTRY PRACTICES AND WORKMANSHIP. DEFECTIVE PRODUCT & INSTALLATION SHALL BE REPLACED AT FURNITURE VENDOR'S SOLE COST. ALL FURNITURE SHALL BE WARRANTED BY MANUFACTURER FOR A PERIOD OF TWELVE (12) MONTHS FROM THE DATE OF DELIVERY UNLESS OTHERWISE SPECIFIED. FURNITURE VENDOR TO FURNISH ALL LABOR AND MATERIALS TO COMPLETE ALL WORK SHOWN ON THE DRAWINGS INCLUDING BUT NOT LIMITED TO HARDWARE, FASTENINGS, SUPPORTS, CONNECTIONS, ATTACHMENTS, BLOCKING AND ADHESIVES AS RECOMMENDED BY MANUFACTURER. SUBMITTALS (DRAWINGS): FURNITURE VENDOR MUST SUBMIT SHOP DRAWINGS FOR REVIEW AND APPROVAL BY ARCHITECT AND REVIEW BY MEP ENGINEER AND GENERAL CONTRACTOR, INCLUDING CUT SHEETS OF ELECTRIFIED COMPONENTS. SHOP DRAWINGS MUST SHOW LOCATIONS OF ELECTRICAL COMPONENTS, PLAN(S), ELEVATIONS, FINISHES, DETAILS. DRAWINGS MUST SHOW DIMENSIONS. FURNITURE VENDOR IS REQUIRED TO ATTEND PROJECT MEETINGS WITH THE GENERAL CONTRACTOR AND ELECTRICIAN.

ELECTRICAL WORK A. FURNITURE VENDOR IS RESPONSIBLE FOR ALL ELECTRICAL WORK FOR THE FURNITURE SYSTEMS REQUIRED IN CONJUNCTION WITH THE INSTALLATION SERVICES HEREUNDER. THIS INCLUDES ALL ELECTRICAL COMPONENTS, THE CONNECTION OF (AND BETWEEN) ALL OFFICE FURNITURE SYSTEMS, INSTALLATION OF POWER HOOKUPS & THE DISPOSAL OF ALL TRASH RELATED TO ANY ELECTRICAL COMPONENTS. CONDITIONS OF JOBSITE A. IT IS THE RESPONSIBILITY OF THE FURNITURE VENDOR TO COORDINATE WITH CLIENT TO ASSURE THE JOBSITE IS CLEAN, CLEAR AND FREE OF DEBRIS PRIOR TO DELIVERY AND INSTALLATION. DELIVERY AND INSTALLATION A. FURNITURE VENDOR SHALL HAVE A RESPONSIBLE REPRESENTATIVE ON THE JOB SITE AT THE TIME OF ALL DELIVERIES TO RECEIVE AND ACKNOWLEDGE CORRECTNESS OF COUNT AND CONDITION OF MERCHANDISE BEING DELIVERED. REPRESENTATIVE IS TO SUPERVISE THE INSTALLATION OF ALL WORK. B. ALL PROTECTIVE COVERINGS TO BE REMOVED AT THE COMPLETION OF THE DELIVERY AND INSTALLATION. ALL THE SURFACES TO BE CLEANED. C. JOB SITE SERVICES: ELECTRIC CURRENT, HEAT, HOISTING AND/OR ELEVATOR SERVICE WILL BE FURNISHED WITHOUT A CHARGE UNLESS OTHERWISE SPECIFIED. D. FURNITURE VENDOR WILL PROVIDE PACKAGING AND HANDLING FREE OF CHARGE. E. DELIVERY DURING BUSINESS HOURS SHALL BE AGREED AND CONFIRMED WITH THE CLIENT. DELIVERY AND INSTALLATION OUTSIDE NORMAL BUSINESS HOURS OR WEEKEND LABOR WILL BE APPROVED BY THE CLIENT PRIOR TO DELIVERY AND PAID BY THE CLIENT. F. DATE OF THE DELIVERY AND STORAGE OF THE MERCHANDISE IF NECESSARY TO BE APPROVED BY THE CLIENT PRIOR TO SHIPPING. TRASH REMOVAL A. DISPOSAL OF ALL FURNITURE RELATED TRASH IS THE RESPONSIBILITY OF FURNITURE VENDOR, GC TO COORDINATE.

DIVISION 13 - SPECIAL CONSTRUCTION IN ADDITION TO DIVISION 13 GENERAL NOTES FOR ALL SYSTEMS: A. ALL MATERIALS, PRODUCTS, AND METHODS TO BE DELIVERED, HANDLED, AND INSTALLED PER MFR'S SPECIFICATIONS, FREE OF DEFECT, AND SHALL COMPLY WITH APPLICABLE LOCAL LAWS AND BEST INDUSTRY PRACTICES AND WORKMANSHIP. DEFECTIVE PRODUCT & INSTALLATION SHALL BE REPLACED AT CONTRACTOR'S SOLE COST B. SUBMITTALS (PRODUCT DATA): B.1. SUBMIT MFR'S DATA SHEETS AND CATALOGUE CUTS FOR ALL ITEMS INCLUDING BUT NOT LIMITED TO SPRINKLERS, SMOKE DETECTORS, FIRE PULLS, ETC. JRA TO SELECT ALL DEVICE COLORS. C. SUBMITTALS (DRAWINGS): C.1. SUBMIT SHOP DRAWINGS SHOWING LOCATIONS AND PLAN(S). SUBMIT SEPARATE DRAWINGS FOR UNLIKE SYSTEMS (FOR EXAMPLE PREACTION SPRINKLER SYSTEMS). CONFIRM REQUIREMENTS WITH ARCHITECT & MEP ENGINEER. D. CONTRACTOR TO FURNISH ALL LABOR AND MATERIALS TO COMPLETE ALL WORK SHOWN ON THE DRAWINGS INCLUDING BUT NOT LIMITED TO DEVICES, FASTENINGS, SUPPORTS, ATTACHMENTS, AND BLOCKING AS RECOMMENDED BY MFR. E. ALL SPRINKLER HEADS ETC. ARE TO BE LOCATED ON CENTER OF ACT UON. COORDINATE EQUIPMENT LOCATIONS WITH OTHER TRADES INCLUDING BUT NOT LIMITED TO ELECTRICAL AND MECHANICAL. F. DO NOT CUT OR ABRADE FINISHES WHICH CANNOT BE COMPLETELY RESTORED IN FIELD. G. AT COMPLETION OF THE PROJECT, REMOVE ALL PROTECTIVE COVERINGS AND CLEAN EXPOSED SURFACES. H. ALL WORK AND MATERIALS (INCLUDING INSTALLATION, MATERIAL & WORKMANSHIP WARRANTY) INCLUDED IN THE CONTRACT DOCUMENTS SHALL BE UNCONDITIONALLY GUARANTEED AGAINST DEFECTS IN MATERIALS AND WORKMANSHIP FOR THE PERIOD STIPULATED IN THE MFR'S SPECIFICATIONS OR FOR ONE YEAR, WHICHEVER IS LONGER.

DIVISION 14 - CONVEYING SYSTEMS NOT IN USE

DIVISION 15 - MECHANICAL 15.90.00 HVAC IN ADDITION TO DIVISION 15 GENERAL NOTES FOR ALL SYSTEMS: A. ALL MATERIALS, PRODUCTS, AND METHODS TO BE DELIVERED, HANDLED, AND INSTALLED PER MFR'S SPECIFICATIONS, FREE OF DEFECT, AND SHALL COMPLY WITH APPLICABLE LOCAL LAWS AND BEST INDUSTRY PRACTICES AND WORKMANSHIP. DEFECTIVE PRODUCT & INSTALLATION SHALL BE REPLACED AT CONTRACTOR'S SOLE COST B. SUBMITTALS (PRODUCT DATA): B.1. SUBMIT MFR'S DATA SHEETS AND CATALOGUE CUTS FOR ALL HVAC EQUIPMENT INCLUDING BUT NOT LIMITED TO DIFFUSERS, CONTROLS, DUCTS, DAMPERS, FANS, VENILATION HOODS. JRA TO SELECT ALL VISIBLE EQUIPMENT COLORS & FINISHES. C. SUBMITTALS (DRAWINGS): D. SUBMIT SHOP DRAWINGS SHOWING LOCATIONS, PLAN(S), SCHEDULES, ELEVATIONS, DETAILS. DRAWINGS MUST SHOW CEILING HEIGHTS AND HEIGHTS AND DEPTHS OF DUCTWORK. E. GC TO VERIFY ALL DIMENSION AND CONDITIONS. NOTIFY JRA OF ANY DISCREPANCIES PRIOR TO WORK. COORDINATE WITH LIGHT FIXTURES, AV EQUIPMENT, STRUCTURAL WORK ETC... F. CONTRACTOR TO COORDINATE WITH ELECTRICIAN, AND HVAC CONTRACTOR G. COVERS FOR CONVECTION HEATING AND COOLING UNITS TO BE PER MFR'S RECOMMENDED DIMENSION. H. CONTRACTOR TO FURNISH ALL LABOR AND MATERIALS TO COMPLETE ALL WORK SHOWN ON THE DRAWINGS INCLUDING BUT NOT LIMITED TO EQUIPMENT, INSULATION, LINERS, FASTENINGS, SUPPORTS, ATTACHMENTS, AND BLOCKING AS RECOMMENDED BY MFR. I. DO NOT CUT OR ABRADE FINISHES WHICH CANNOT BE COMPLETELY RESTORED IN FIELD. J. AT COMPLETION OF THE PROJECT, REMOVE ALL PROTECTIVE COVERINGS AND CLEAN EXPOSED SURFACES. K. ALL WORK AND MATERIALS (INCLUDING INSTALLATION, MATERIAL & WORKMANSHIP WARRANTY) INCLUDED IN THE CONTRACT DOCUMENTS SHALL BE UNCONDITIONALLY GUARANTEED AGAINST DEFECTS IN MATERIALS AND WORKMANSHIP FOR THE PERIOD STIPULATED IN THE MFR'S SPECIFICATIONS OR FOR ONE YEAR, WHICHEVER IS LONGER. L. PROVIDE BALANCING REPORT AT COMPLETION OF WORK.

DIVISION 22 - PLUMBING GENERAL NOTES FOR ALL DEVICES AND SYSTEMS: A. ALL MATERIALS, PRODUCTS, AND METHODS TO BE DELIVERED, HANDLED, AND INSTALLED PER MFR'S SPECIFICATIONS, FREE OF DEFECT, AND SHALL COMPLY WITH APPLICABLE LOCAL LAWS AND BEST INDUSTRY PRACTICES AND WORKMANSHIP. DEFECTIVE PRODUCT & INSTALLATION SHALL BE REPLACED AT CONTRACTOR'S SOLE COST B. SUBMITTALS (PRODUCT DATA): B.1. SUBMIT MFR'S DATA SHEETS AND CATALOGUE CUTS FOR ALL PLUMBING FIXTURES AND SYSTEMS. JRA TO SELECT ALL VISIBLE FIXTURE COLORS & FINISHES. C. SUBMITTALS (DRAWINGS): C.1. SUBMIT SHOP DRAWINGS SHOWING LOCATIONS, PLAN(S), SCHEDULES, ELEVATIONS, DETAILS. SUBMIT SEPARATE DRAWINGS FOR UNLIKE SYSTEMS (FOR EXAMPLE PREACTION SPRINKLER SYSTEMS). CONFIRM REQUIREMENTS WITH ARCHITECT & MEP ENGINEER. D. SWIMMING POOL PIPING, PUMPS, WATER TREATMENT EQUIPMENT, CONTROLS TO BE COORDINATED WITH MEP ENGINEER, ARCHITECT, AND VENDOR E. GC TO VERIFY ALL DIMENSION AND CONDITIONS IN EXISTING SPACES RECEIVING NEW FIXTURES PRIOR TO ORDER. NOTIFY JRA OF ANY DISCREPANCIES OR PROBLEMS WITH APPROVED FIXTURES PRIOR TO WORK. COORDINATE DRAIN OPENINGS WITH ARCHITECT AND PLUMBER. F. CONFIRM DIMENSIONS AND DRAIN OPENINGS FOR SHOWER PANS/BATHTUBS/LAVATORIES WITH VENDOR AND ARCHITECT PRIOR TO WORK G. CONTRACTOR TO FURNISH ALL LABOR AND MATERIALS TO COMPLETE ALL WORK SHOWN ON THE DRAWINGS INCLUDING BUT NOT LIMITED TO DEVICES, FASTENINGS, SUPPORTS, ATTACHMENTS, AND BLOCKING AS RECOMMENDED BY MFR. H. DO NOT CUT OR ABRADE FINISHES WHICH CANNOT BE COMPLETELY RESTORED IN FIELD. I. AT COMPLETION OF THE PROJECT, REMOVE ALL PROTECTIVE COVERINGS AND CLEAN SURFACES. J. ALL WORK AND MATERIALS (INCLUDING INSTALLATION, MATERIAL & WORKMANSHIP WARRANTY) INCLUDED IN THE CONTRACT DOCUMENTS SHALL BE UNCONDITIONALLY GUARANTEED AGAINST DEFECTS IN MATERIALS AND WORKMANSHIP FOR THE PERIOD STIPULATED IN THE MFR'S SPECIFICATIONS OR FOR ONE YEAR, WHICHEVER IS LONGER.

MEP ENGINEER:

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

EXPEDITER:

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

DIVISION 16 - ELECTRICAL GENERAL NOTES FOR ALL DEVICES AND SYSTEMS: A. ALL MATERIALS, PRODUCTS, AND METHODS TO BE DELIVERED, HANDLED, AND INSTALLED PER MFR'S SPECIFICATIONS, FREE OF DEFECT, AND SHALL COMPLY WITH APPLICABLE LOCAL LAWS AND BEST INDUSTRY PRACTICES AND WORKMANSHIP. DEFECTIVE PRODUCT & INSTALLATION SHALL BE REPLACED AT CONTRACTOR'S SOLE COST B. SUBMITTALS (PRODUCT DATA): B.1. SUBMIT MFR'S DATA SHEETS AND CATALOGUE CUTS FOR ALL ELECTRICAL EQUIPMENT INCLUDING BUT NOT LIMITED TO LIGHT FIXTURES, COVER PLATES, JRA TO SELECT ALL VISIBLE EQUIPMENT COLORS & FINISHES. C. SUBMITTALS (DRAWINGS): D. SUBMIT SHOP DRAWINGS SHOWING LOCATIONS, PLAN(S), SCHEDULES, ELEVATIONS, DETAILS. DRAWINGS MUST SHOW CEILING HEIGHTS AND HEIGHTS OF FIXTURES. E. GC TO VERIFY ALL DIMENSION AND CONDITIONS. NOTIFY JRA OF ANY DISCREPANCIES PRIOR TO WORK. COORDINATE LIGHT FIXTURES WITH AV EQUIPMENT, HVAC EQUIPMENT, STRUCTURAL WORK ETC... F. GC TO VERIFY FURNITURE FEED LOCATIONS WITH FURN VENDOR AND ARCHITECT PRIOR TO INSTALLATION G. CONTRACTOR TO FURNISH ALL LABOR AND MATERIALS TO COMPLETE ALL WORK SHOWN ON THE DRAWINGS INCLUDING BUT NOT LIMITED TO EQUIPMENT, INSULATION, LINERS, FASTENINGS, SUPPORTS, ATTACHMENTS, AND BLOCKING AS RECOMMENDED BY MFR. H. ALL SWITCH AND OUTLET COVER PLATES TO BE SCREWLESS. SPEC TO BE LUTRON CLARO. SUBMIT SAMPLE TO JRA FOR APPROVAL. I. GC TO CAP ALL NON-ACTIVE OUTLETS AS PART OF CONTRACT J. COORDINATE ELECTRICAL REQUIREMENTS FOR ALL FURNITURE, SYSTEMS FURNITURE, CASEGOODS, MILLWORK, AND WOODWORK. K. DO NOT CUT OR ABRADE FINISHES WHICH CANNOT BE COMPLETELY RESTORED IN FIELD. L. AT COMPLETION OF THE PROJECT, REMOVE ALL PROTECTIVE COVERINGS AND CLEAN EXPOSED SURFACES. M. ALL WORK AND MATERIALS (INCLUDING INSTALLATION, MATERIAL & WORKMANSHIP WARRANTY) INCLUDED IN THE CONTRACT DOCUMENTS SHALL BE UNCONDITIONALLY GUARANTEED AGAINST DEFECTS IN MATERIALS AND WORKMANSHIP FOR THE PERIOD STIPULATED IN THE MFR'S SPECIFICATIONS OR FOR ONE YEAR, WHICHEVER IS LONGER.

CLIENT:

DIVISION 21 - FIRE SUPPRESSION GENERAL NOTES FOR ALL DEVICES AND SYSTEMS: A. ALL MATERIALS, PRODUCTS, AND METHODS TO BE DELIVERED, HANDLED, AND INSTALLED PER MFR'S SPECIFICATIONS, FREE OF DEFECT, AND SHALL COMPLY WITH APPLICABLE LOCAL LAWS AND BEST INDUSTRY PRACTICES AND WORKMANSHIP. DEFECTIVE PRODUCT & INSTALLATION SHALL BE REPLACED AT CONTRACTOR'S SOLE COST B. SUBMITTALS (PRODUCT DATA): B.1. SUBMIT MFR'S DATA SHEETS AND CATALOGUE CUTS FOR ALL ITEMS INCLUDING BUT NOT LIMITED TO SPRINKLERS, SMOKE DETECTORS, FIRE PULLS, ETC. JRA TO SELECT ALL DEVICE COLORS. C. SUBMITTALS (DRAWINGS): C.1. SUBMIT SHOP DRAWINGS SHOWING LOCATIONS AND PLAN(S). SUBMIT SEPARATE DRAWINGS FOR UNLIKE SYSTEMS (FOR EXAMPLE PREACTION SPRINKLER SYSTEMS). CONFIRM REQUIREMENTS WITH ARCHITECT & MEP ENGINEER. D. CONTRACTOR TO FURNISH ALL LABOR AND MATERIALS TO COMPLETE ALL WORK SHOWN ON THE DRAWINGS INCLUDING BUT NOT LIMITED TO DEVICES, FASTENINGS, SUPPORTS, ATTACHMENTS, AND BLOCKING AS RECOMMENDED BY MFR. E. ALL SPRINKLER HEADS ETC. ARE TO BE LOCATED ON CENTER OF ACT UON. COORDINATE EQUIPMENT LOCATIONS WITH OTHER TRADES INCLUDING BUT NOT LIMITED TO ELECTRICAL AND MECHANICAL. F. DO NOT CUT OR ABRADE FINISHES WHICH CANNOT BE COMPLETELY RESTORED IN FIELD. G. AT COMPLETION OF THE PROJECT, REMOVE ALL PROTECTIVE COVERINGS AND CLEAN EXPOSED SURFACES. H. ALL WORK AND MATERIALS (INCLUDING INSTALLATION, MATERIAL & WORKMANSHIP WARRANTY) INCLUDED IN THE CONTRACT DOCUMENTS SHALL BE UNCONDITIONALLY GUARANTEED AGAINST DEFECTS IN MATERIALS AND WORKMANSHIP FOR THE PERIOD STIPULATED IN THE MFR'S SPECIFICATIONS OR FOR ONE YEAR, WHICHEVER IS LONGER.

04.28.17

ISSUED FOR BID

PROJECT

CANCER RESEARCH INSTITUTE 29 BROADWAY, 4TH FLOOR, NEW YORK, NY 10006 SHEET TITLE

4TH FLOOR GENERAL NOTES SEAL & SIGNATURE

01.17.2017 1505-16 KR HG AS NOTED

000

GENERAL GRAPHIC SYMBOLS PRIVATE OFFICE

ROOM AREA NUMBER

02-26

KEY NOTE

DEMOLITION/CONSTRUCTION GRAPHIC GRAPHIC SYMBOLS

REFLECTED CEILING GRAPHIC SYMBOLS

EXISTING MATERIAL TO BE REMOVED

EXISTING DOOR TO BE REMOVED

POWER & SIGNAL GRAPHIC SYMBOLS

CEILING TYPE (EX= EXISTING, ACT= ACOUSTICAL TILE AND GRID, GB = GYPSUM BOARD 5/8" THICK)

DUPLEX OUTLET

CEILING HEIGHT

QUAD OUTLET

ELEVATION SYMBOL 2 1

3 A000.00

DRAWING NUMBER

SIMPLEX OUTLET CHANGE IN CEILING HEIGHT AND/OR MATERIAL

EXISTING WALL TO REMAIN

GFI

ELEVATION NUMBER

SECTION SYMBOL 1 A000.00

SECTION NUMBER DRAWING NUMBER

DETAIL SYMBOL AREA SHOWN IN DETAIL

COMBINATION VOICE/DATA OUTLET

STANDARD PARTITION: ONE LAYER OF 5/8" GYPSUM BOARD TYPE X SCREW ATTACHED VERTICALLY BOTH SIDE TO 2-1/2" STEEL STUDS, 16" OC.C. FROM FROM SLAB TO 6" ABOVE CEILING. (SEE PARTITION TYPE 1/A-500 FOR MORE INFORMATION) (FOR ALL OTHER PARTITIONS SEE DRAWING A-500 FOR MORE INFORMATION)

ACOUSTICAL TILE CEILING AND GRID CABLE TV OUTLET

DRAWING TITLE

FLUSH MOUNTED FLOOR OUTLETS INTERCOM LAMINATED GWB CEILING 5/8" THICK

DOOR RELEASE

SFT

START FULL TILE

CARD READER

PARTITION TYPE (SEE PARTITIONS DETAILS DRAWING A-500 FOR MORE INFORMATION)

MAGNETIC LOCK

ELECTRIC STRIKE

DOOR NUMBER (SEE DOOR SCHEDULE FOR MORE INFORMATION)

APPLIANCE SYMBOL (SEE APPLIANCE SCHEDULE FOR MORE INFORMATION)

REVISION NUMBER

ALIGN SURFACES CENTER LINE

EXPEDITER:

KEY OVERRIDE

DRAWING SCALE DRAWING NUMBER

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

GYPSUM BOARD CEILING 5/8" THICK

NEW DOOR

SCALE: 1/8"=1'-0"

REVISED AREA

MEP ENGINEER:

SWITCH

DRAWING TAG SYMBOL

DEDICATED DUPLEX OUTLET

EXISTING DOOR TO REMAIN

DRAWING NUMBER

TITLE

GFI DUPLEX OUTLET

DIMMING SWITCH

DETAIL NUMBER 1 A000.00

ARCHITECT

PLUMBING SYMBOL (SEE SCHEDULE FOR MORE INFORMATION)

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

EQUIPMENT SYMBOL (SEE EQUIPMENT SCHEDULE FOR MORE INFORMATION)

ALIGN WITH ESTABLISHED SURFACES

DIAMETER PLUS/MINUS DISTANCE ABOVE FINISH FLOOR (AFF)

NEW MILLWORK. SUBMIT SAMPLES AND SHOP DRAWINGS FOR ARCHITECT'S REVIEW AND APPROVAL PRIOR TO FABRICATION. (SEE ELEVATIONS AND DETAILS FOR MORE INFORMATION)

ELEVATION GRAPHIC SYMBOLS

CLIENT:

ELEVATION DATUM POINT N E D F T M R S

NEW WORK EXISTING TO REMAIN EXISTING TO BE DEMOLISHED FUTURE WORK TEMPORARY WORK ITEMS TO BE MOVED RELOCATED ITEMS ITEMS TO BE SALVAGED

CONSTRUCTION NOTES

GLASS

SEE LIGHTING SCHEDULE FOR ADDITIONAL LIGHT SYMBOLS REFLECTED CEILING PLAN NOTES

FINISH GRAPHIC SYMBOLS

TEL./ELEC. & FURN. PLAN NOTES 1. EQUIPMENT AND FURNITURE ARE NOT IN CONTRACT. (U.N.O.).

ALL DIMENSIONS ARE FROM FIELD SURVEYS, NOTIFY ARCHITECT OF ANY DISCREPANCIES BETWEEN SITE CONDITIONS AND CONTRACT DOCUMENTS FOR EVALUATION BEFORE THE AFFECTED CONSTRUCTION IS PUT IN PLACE. CONTRACTOR SHALL NOT SCALE DOCUMENTS.

1. THIS DRAWING IS INTENDED TO DEPICT ARCHITECTURAL ELEMENTS ONLY. MECHANICAL AND ELECTRICAL COMPONENTS, IF SHOWN, ARE TO ILLUSTRATE GENERAL INTENT ONLY. 2. GENERAL CONTRACTOR SHALL REFER TO ENGINEERING DRAWINGS FOR ADDITIONAL INFORMATION ON NUMBER OF SWITCHES, CIRCUITING & LIFE SAFETY DEVICES. NOTIFY ARCHITECT OF ANY DISCREPANCIES PRIOR TO INSTALLATION.

2. ALL APPLIANCES ARE PART OF CONTRACT (U.N.O.). 3. NOTIFY ARCHITECT OF ANY DISCREPANCIES PRIOR TO INSTALLATION.

ALL EXISTING CONDITIONS TO BE REMOVED AS REQUIRED AND INCLUDED IN BASE BID.

ARCHITECT TO APPROVE CHALK LINE PARTITION LAYOUT BEFORE SECURING METAL TRACKS. NOTIFY ARCHITECT AT LEAST THREE (3) DAYS IN ADVANCE TO SCHEDULE LAYOUT REVIEW.

3. ALL FIXTURES ARE NEW (U.N.O.). 4. ALL SWITCHES TO BE 3'-2" A.F.F. (U.N.O.).

5. SUBMIT SPECIFICATION CUTS FOR COVER PLATES & DEVICES FOR ARCHITECT'S FOR APPROVAL.

GENERAL CONTRACTOR TO PROVIDE TWO (2) 25LB TYPE FIRE EXTINGUISHERS APPROVED FOR TYPE A, B, & C FIRES AND SHALL BE KEPT AND MAINTAINED ON PREMISES FOR THE DURATION OF CONTRACT.

5. ALL SPRINKLER HEADS, EXIT SIGNS, DOWN LIGHTS, ETC. ARE TO BE LOCATED ON THE CENTER OF ACOUSTICAL TILE. (U.N.O.).

6. WALL MOUNTED ELECTRICAL AND/OR TELEPHONE OUTLETS ARE TO BE MOUNTED VERTICALLY AT 18" A.F.F. (U.N.O.).

SAND SMOOTH AND PREP ALL SURFACES TO RECEIVE NEW PAINT FINISHES INCLUDING CONVECTOR COVERS, HM DOORS/FRAMES & ELEVATOR DOOR/FRAME.

6. SEE APPROPRIATE ENGINEERING DRAWINGS FOR ALL MECHANICAL, ELECTRICAL AND FIRE PROTECTION EQUIPMENT INFORMATION.

7. ALL TELEPHONE AND LOW VOLTAGE WALL OUTLETS TO BE PROVIDED WITH A BOX AND DRAG LINE AND AN EMPTY CONDUIT STUB-UP.

7. ALL FLUORESCENT LAMPS TO BE WARM WHITE/3000 DEGREES KELVIN, LONG LIFE ENERGY SAVINGS, & FROM A SINGLE MANUFACTURER. (U.N.O.).

8. ALL DATA CABLES TO BE SUPPLIED AND INSTALLED BY OTHERS. (U.N.O)

8. ELECTRIC DEVICES' COLORS AND FINISHES TO BE SELECTED BY ARCHITECT.

9. ALL DEVICES ARE ASSUMED WALL MOUNTED, UNLESS SHOWN ON FURNITURE. VERIFY WITH ARCHITECT.

9. ALL NEW STROBE LIGHTS TO BE RECESSED IN NEW OR EXISTING WALLS. INCLUDE CHOPPING AS REQUIRED.

10. CAP ALL NON ACTIVE OUTLETS.

10. SEE POWER/SIGNAL PLAN FOR ADDITIONAL LIGHTING (UNDER CABINETS).

11. ALL SWITCH, THERMOSTAT, AND OUTLET LOCATIONS/HEIGHTS TO BE REVIEWED IN THE FIELD WITH ARCHITECT PRIOR TO INSTALLATION.

DO NOT CHOP CORE WALLS AT NEW PARTITIONS PERPENDICULAR TO CORE WALLS, PROVIDE NEOPRENE GASKET AT THIS CONDITION. FURRING OF WALLS TO CORE MUST BE INDEPENDENTLY SUPPORTED.

GENERAL CONTRACTOR TO THOROUGHLY CLEAN AND VACUUM AT THE END OF THE JOB.

ALL FLOOR FLASH PATCHING BY GENERAL CONTRACTOR.

GENERAL CONTRACTOR TO INCLUDE ALL CUTTING & PATCHING FOR MECHANICAL SYSTEM, SECURITY, COMMUNICATIONS, LIGHTING & ELECTRICAL SYSTEMS.

11. SUBMIT CEILING GRID SAMPLE FOR ARCHITECT'S APPROVAL.

ALL PERIMETER WINDOW MULLIONS TO BE CLEANED & REPAIRED AS REQUIRED TO MATCH EXISTING.

12. PROVIDE 18"X18" MINIMUN ACCESS PANEL IN ALL G.W.B. CEILINGS AS REQUIRED TO ACCESS ALL BASE BUILDING AND OR NEW MECHANICAL SYSTEMS. INCLUDE FOUR (4) ACCESS PANELS IN BASE BID AND SUBMIT UNIT PRICE (MATERIAL AND INSTALLATION).

10.

11.

REFURBISH DAMAGED EXISTING WINDOWS AND MULLIONS (REMOVE OLD PAINT).

12.

GENERAL CONTRACTOR TO ENSURE ALL FLOOR OPENINGS ARE FULLY FIRE STOPPED.

13.

REFER TO POWER/SIGNAL/FURN PLAN FOR EQUIPMENT LOCATIONS THAT REQUIRE BLOCKING IN WALLS.

14.

ALL EXISTING COLUMNS TO BE LAMINATED OR FURRED OUT WITH 5 8" THICK GYP. BOARD. ALL EXISTING PERIMETER WALLS AND PIERS TO BE LAMINATED OR FURRED OUT AND RECEIVE NEW 5 8" GYP. BOARD, APPLY PLASTER WHERE MISSING BEHIND CONVECTORS.

15.

G.C. TO INCLUDE ALL CONTROLLED INSPECTIONS REQUIRED IN BASE BID.

16.

G.C. TO SEAL ALL WALL AND SLAB PENETRATIONS (EXISTING AND ONES CREATED ON THE JOB) UPON COMPLETION OF WORK.

17.

PROVIDE 18"X18" ACCESS DOORS FOR BUILDING SYSTEMS.

FLOOR FINISH. SEE FINISH SCHEDULE FOR MORE INFORMATION BASE FINISH. SEEE FINISH SCHEDULE FOR MORE INFORMATION

WALL FINISH. SEE FINISH SCHEDULE FOR MORE INFORMATION CEILING FINISH. SEE FINISH SCHEDULE FOR MORE INFORMATION

4. GENERAL CONTRACTOR TO COORDINATE THIS PLAN WITH ELECTRICAL PLANS. NOTIFY ARCHITECT OF ANY DISCREPANCIES.

F: B: W: C:

MATERIAL FINISH. SEE FINISH SCHEDULE FOR MORE INFORMATION. CHANGE IN FLOOR MATERIALS.

E GL PL PP PT SS WD

EXISTING GLASS PLASTIC LAMINATE PREFINISHED PLYWOOD PAINTED SIMULATED STONE WOOD

12. GENERAL CONTRACTOR TO VERIFY AND COORDINATE WITH ARCHITECT/ COMMUNICATIONS VENDOR/ DATA VENDOR/ SECURITY VENDOR/ AV VENDOR PRIOR TO INSTALLATION OF ANY DEVICES. 13. ALL OUTLETS SHOWN ARE NEW (U.N.O.). 14. GENERAL CONTRACTOR TO VERIFY ALL "APPROVED" EQUIPMENT AND APPLIANCE REQUIREMENTS/DIMENSIONS PRIOR TO FABRICATION OF CABINETRY, OUTLET INSTALLATION AND CONSTRUCTION OF WALLS.

FINISH PLAN NOTES 1

INSTALL AND APPLY ALL PRODUCTS AS PER MANUFACTURER'S SPECIFICATIONS. (U.N.O.).

15. GENERAL CONTRACTOR TO VERIFY FURNITURE FEED LOCATIONS W/ FURN VENDOR & ARCHITECT PRIOR TO INSTALLATION.

ALL EXPOSED SURFACES TO BE PAINTED EGGSHELL FINISH INCLUDING DRAPERY POCKETS, WALLS, SOFFITS, ETC. (U.N.O.).

16. GENERAL CONTRACTOR COORDINATE WITH VENDORS TO PROVIDE CHANNELING AT EXSITING WALLS AND SLABS AS REQUIRED FOR TELEPHONE/DATA, AUDIO/VISUAL, AND SECURITY CABLING.

ALL WALLS & SURFACES SHALL BE PROPERLY PREPARED, (SPACKLED PLASTERED, SANDED & PRIMED), PRIOR TO RECEIVING NEW PAINT AND WALLCOVERING.

GENERAL CONTRACTOR WILL SUPPLY AND INSTALL ALL CARPET, VINYL TILES, WALL BASE, SADDLES AND TRANSITION STRIPS IN AREAS INDICATED.

CARPET CONTRACTOR & GENERAL CONTRACTOR TO COORDINATE INSTALLATION SCHEDULES OF GENERAL CONSTRUCTION & MECHANICAL/ ELECTRICAL TRADES WITH CARPET INSTALLATION.

17. SEE MECHANICAL AND ELECTRICAL DRAWINGS FOR POWER REQUIREMENTS IN COMMUNIACTIONS AND ELECTRICAL CLOSETS. 18. REFER TO REFLECTED CEILING PLAN FOR FURTHER ELECTRICAL REQUIREMENTS FOR CEILING MOUNTED EQUIPMENT.

GENERAL CONTRACTOR TO SUBMIT THREE (3) 12" X 12" FINISH SAMPLES FOR APPROVAL BY ARCHITECT PRIOR TO FINISH MATERIALS PURCHASE (JANKO RASIC ARCHITECTS).

19. ELECTRICIAN TO FILE THE ELECTRICAL DRAWINGS WITH THE BEC.

ALL PAINTED METAL SURFACES- CONVECTOR COVERS, METAL SURFACES DOORS FRAMES & FIN TUBE ENCLOSURES TO BE PAINTED IN A SEMI-GLOSS ENAMEL FINISH. (U.N.O.).

CONTINUE ALL SPACE FINISHES INTO ADJOINING CLOSETS/STORAGE ROOM. (U.N.O.)

PATCH AND REPAIR ALL SURFACES AFTER INSTALLING SECURITY, FIRE ALARM & COMMUNICATION DEVICES.

10.

ALL WALLS TO BE PRIMED PRIOR TO APPLICATION OF FINISH WALL TREATMENT.

11.

BASE, CEILING TILES, VCT, CERAMIC TILE, PLASTIC LAMINATE & PAINT COLORS ARE MANUFACTURER'S STANDARD COLORS & AS SELECTED BY ARCHITECT/OWNER.

12.

PROVIDE ONE (1) COAT OF PRIMER PLUS TWO (2) COATS OF PAINT.

13.

G.C. TO INCLUDE FLASH PATCHING OF FLOOR IN ALL AREAS AS NEEDED.

14.

PATCH & PAINT AREAS AFFECTED BY DEMOLITION & CONSTRUCTION TO MATCH EXISTING.

15.

CONTRACTOR SHALL PROVIDE 10% ATTIC STOCK OF CARPET TILE TO BE STORED FOR TENANT.

16.

SEE FINISH PLAN / ELEVATIONS/ DETAILS FOR MILLWORK FINISHES.

04.28.17

ISSUED FOR BID

PROJECT

CANCER RESEARCH INSTITUTE 29 BROADWAY, 4TH FLOOR, NEW YORK, NY 10006 SHEET TITLE

4TH FLOOR GENERAL NOTES 01.17.2017 1505-16 KR

SEAL & SIGNATURE

HG AS NOTED

A-004.00 1505-16GN04-A-004.00

000

NORTH

SEE DRAWING A-004 FOR SYMBOL LEGEND AND NOTES.

PLAN NOTES

KEY NOTES

UPGRADE EXISTING PARTITION TO 1HR (TYPE 1) VIF. PATCH / PROVIDE ONE LAYER OF 5/8" THK. GWB EACH SIDE TO UNDERSIDE OF SLAB.

EXTEND EXISTING PARTITION TO UNDERSIDE OF SLAB. PROVIDE INSULATION.

EXISTING GLASS DOORS AND FULL-HEIGHT GLASS PARTITION TO REMAIN. (PROTECT AS REQUIRED)

EXISTING FINISH WOOD COLUMN ENCLOSURE AND RECEPTION DESK TO REMAIN. (PROTECT AS REQUIRED)

ARCHITECT

ALL COLUMNS AND BEAMS TO BE FIRE-RATED TO MATCH EXISTING (vif) PATCH AS REQUIRED AND INCLUDED IN BID. GC TO INCLUDE IN CONTRACT ACCESS DOORS FOR ALL BUILDING VALVES INSIDE COLUMNS OR PARTITIONS (VIF) AND REVIEW WITH BUILDING MANAGEMENT PRIOR TO SUBMITTAL OF BID. ALL EXISTING CONVECTORS COVERS TO REMAIN. PROTECT AS REQUIRED. LAMINATE / PATCH ALL EXISTING WALLS, PORTIONS OF COLUMNS AS REQUIRED FOR SMOOTH SURFACE. (REMOVE ANY WALL COVERING AS REQUIRED)

2. 3. 4.

MEP ENGINEER:

MEN

ADA

04-38

CORR.

04-37

STORAGE

04-36

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

OPEN WORKSTATIONS

04-28

04-27C

LOUNGE

OFFICE

04-22

04-53

OFFICE

04-21

04-20

BAR

04-51 DN 4 A-202

SERVICE ELEV. 9

EX CL

PANTRY

04-50

ELEV. 4

P1 SINK

ELEV. 8

MEN

EX OFFICE

REF

04-19

C I N

N. STAIR ELEV. 3

OPEN BENCH WORKSTATIONS

WOMEN

ELEV. 7

CORRIDOR

04-39

04-49 ELEVATOR LOBBY

ELEV. 2

S. STAIR OFFICE

20 OPEN WORKSTATIONS

OPEN WORKSTATIONS

04-27A

04-27B

BAR

30A

OFFICE

04-29 OFFICE

04-30A

04-23

04-48 WOMEN

1 A-202

CORRIDOR

04-30 ELEV. 1 OFFICE

04-47

ELEV. 5

04-46

46A

04-44A

COATS A

04-01A 04-45 MECH

44B

MECH

04-24

3 2

A202.00

REF

04-01B

MEETING ROOM

04-01

OFFICE

04-16

31B

COPY / PRINT

04-35A

04-40

THE CONTRACTOR IS RESPONSIBLE FOR: CONFIRMING AND CORRELATING ALL QUANTITIES AND DIMENSIONS.

COPY

35B

COATS B

OPEN WORKSTATIONS

04-35B

04-25A

04-25B

04-25C

OFFICE

04-15

WAITING

EXTG.

7 A-502

35A

04-41

RECEPTION

01B

04-26 16

04-00 COATS A

CORRIDOR

04-44

04-43

04-33

CORR.

OFFICE

04-44B

04-35

04-34

OFFICE

EXTG.

04-17

04-31 SINK

PANTRY

01A

OFFICE

COATS A

STOR

44A

COATS B

04-46A

COATS A

BOARD ROOM

CORRIDOR

CLIENT:

31A 32 04-32

CORRIDOR

CLOS.

FPSC

AT CLG.

ELEC. CLOS.

EXTG.

THOMAS ARTS

04-18

CLOSET A

ELEV. 6

30B

04-27

CLOSET B

04-30B

04-52

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

OFFICE

EXPEDITER:

ELEC. CL

1 A-201 04

14 04-25 CORRIDOR

13 OFFICE

04-14

2 A-501

04-42

04-02

CONFERENCE

OFFICE

04-03

OFFICE

04-04

04-05

04-06

04-07

04-08

04-09

04-10

04-11

04-12

04-13

OFFICE

16'

PLUMBING FIXTURE SCHEDULE COLLECTION

MODEL

PANTRY SINK

KOHLER

VAULT

K-3894

PANTRY FAUCET

HANSGROHE

TALIS S

06462000

SIZE

CANCER RESEARCH INSTITUTE

NOTES

25"L X 22"W X 6"D 8 7/8" H

STAINLESS STEEL / ADA COMPLIANT, UNDER-MOUNT INSTALLATION, SINGLE HOLE PULL-OUT, FULL AND NEEDLE SPRAY, FIN: POLISHED CHROME, ADA COMPLIANT

LOCATION: BLOCK: LOT: ZONE: MAP:

29 Broadway - 4th Floor NEW YORK, NY 10006 20 01 C5-5 12b

29 BROADWAY, 4TH FLOOR, NEW YORK, NY 10006 SHEET TITLE

4TH FLOOR CONSTRUCTION PLAN WAY

MFR

01.17.2017 1505-16 KR

SEAL & SIGNATURE

BROAD

ITEM

ISSUED FOR BID

PROJECT

PLOT PLAN

TRINITY PL

No.

04.28.17

AREA OF WORK

HG AS NOTED

A-101.00 1505-16CN04-A-101.00

000

NORTH

SEE DRAWING A-004 FOR SYMBOL LEGEND AND NOTES.

NOTE:

KEY NOTES 1

UPGRADE EXISTING PARTITION TO 1HR (TYPE 1) VIF. PATCH / PROVIDE ONE LAYER OF 5/8" THK. GWB EACH SIDE TO UNDERSIDE OF SLAB.

1. CONTRACTOR TO SUBMIT LIGHTING CUTS FOR ARCHITECT'S REVIEW AND APPROVAL DURING THE FIRST WEEK OF CONSTRUCTION.

EXTEND EXISTING PARTITION TO UNDERSIDE OF SLAB. PROVIDE INSULATION.

2. CONTRACTOR TO NOTIFY ARCHITECT OF ANY HEIGHT & CLEARANCE CONFLICT(S) PRIOR TO FINAL CEILING INSTALLATION.

EXISTING GLASS DOORS AND FULL-HEIGHT GLASS PARTITION TO REMAIN. (PROTECT AS REQUIRED)

3. VERIFY CLEARANCES WITH APPROVED DUCT SHOP DRAWINGS.

ARCHITECT

MEP ENGINEER:

MEN

ADA

04-38

04-37

CORR.

STORAGE

04-36

04-28

04-27C

LOUNGE

OFFICE

04-22

04-53

OFFICE

04-21

04-20

L3B L2

L12

ELEV. 4

PANTRY

04-50 DD

SERVICE ELEV. 9

L12

ELEV. 3

04-49 L3B

ELEC. CL

04-52

04-48

S. STAIR

L3B

L1D

04-39

ELEV. 7

C I N

CLOSET B

04-27 D

L14C

L12

OPEN WORKSTATIONS

04-27A

4 A-502

04-27B BAR

04-29

GWB 8'-0"

CLOSET A

ELEV. 6

04-30A

OFFICE

L11

L1C

L13

L15

L12

04-46 CORRIDOR

L7C

S L7A

04-34

04-32

L2 L11

L11

L1C

L15

04-43

L10

L15

COATS B

04-01A

3 A-502

MECH EXISTING (REFER TO MEP)

L11

L14C

L7C

L11

04-01

L7B

04-41

GWB 8'-0"

04-40

MEETING

COATS A

COPY

L10 L13

NOTICE

L13

OPEN WORKSTATIONS

04-35A

THE CONTRACTOR IS RESPONSIBLE FOR: CONFIRMING AND CORRELATING ALL QUANTITIES AND DIMENSIONS.

OFFICE

04-15 L1C

L7C

2 D

L3B

04-25 CORRIDOR

4 A-502

L3B

L2 L12

L1E

L3B

04-25C

L12

L1C

L1A

04-42

04-02

CONFERENCE

OFFICE

L1A

04-03

OFFICE

L1A

04-14

ACT 8'-0"

D D

L1E

D D

OFFICE

ACT 8'-0"

1 A-502

5 A-502

OPEN WORKSTATIONS

04-25B

04-25A

6 A-502

04-16

L1E

L1C

04-00

L13

OFFICE L1C

L14C

RECEPTION

L13

WAITING

04-44B

L1C

PANTRY

L7C

COATS A

04-45

04-44

L12

L7C

CORR.

OFFICE

STOR

L7C

04-44A

04-17

04-46A

COATS A

OFFICE

04-26

ACT 8'-0"

04-31

L13

L1E

L1C

04-24

IT (REFER TO MEP)

L12

04-23

L1B

OFFICE

04-33

ACT 8'-0"

L1B

BOARD ROOM

L7A

EXISTING (REFER TO MEP)

CORR.

L1B

L7B

MECH

CLOS.

L1B

CORRIDOR

L12

04-35

OFFICE L14A

L14B

AT CLG.

ELEC. CLOS.

L12

C I N

L3B

ELEV. 5

04-30

L12

04-47

CORRIDOR

L11

3 A-502

WOMEN

CLIENT:

ELEV. 1

04-18

L1C

L3B

OFFICE

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

CORRIDOR

L11

04-19

ACT 8'-0"

L15

L1C

OFFICE

4 A-502

L3B

L12

WOMEN

ELEVATOR LOBBY

ELEV. 2

OFFICE

L1D

L1C

04-30B

EXPEDITER:

L1D

L7A

L15

OPEN BENCH WORKSTATIONS

L7A

ACT 8'-0"

C I N

N. STAIR OFFICE

L12

ELEV. 8

MEN

L10

D D

04-51

D D

BAR

L14C

L3B

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

OPEN WORKSTATIONS

L1A

04-04

04-05

04-06

04-07

04-08

04-09

04-10

04-12

OFFICE

04-11

04-13

OFFICE

L1C

16'

Label

Qty

L1A

L1B

L1C

L2EM

L3B

Catalog Number

Description

SL4L 4 FLP 80CRI Slot 4 LED, 4ft Length, 30K 800LMF Flushed Lens Position, 80CRI, 3000K LED Boards, 800LMF SL4L 8 FLP 80CRI Slot 4 LED, 8ft Length, 30K 600LMF Flushed Lens Position, 80CRI, 3000K LED Boards, 600LMF SL4L 6 FLP 80CRI Slot 4 LED, 6ft Length, 30K 800LMF Flushed Lens Position, 80CRI, 3000K LED Boards, 800LMF ICO CYL 30/10 2AR LSS 6070D MVOLT UGZ

ICO CYL 30/10 2AR LSS 6070D MVOLT UGZ

S4LID 8FT CRD 1N30 2N30BW EZB WHT

INCITO 2'' CYLINDER, 3000K, 1000LM, 80 CRI, 15 DEG REFRACTOR, 60 x 70 ELLIPTICAL BEAM, SEMI SPECULAR TRIM, INCITO 2'' CYLINDER, 3000K, 1000LM, 80 CRI, 15 DEG REFRACTOR, 60 x 70 ELLIPTICAL BEAM, SEMI SPECULAR TRIM, SLOT 4 PENDANT MOUNT 8' (1) DIRECT NORMAL OUTPUT, 3000K BOARDS (2) INDIRECT NORMAL OUTPUT 3500K, BOARDS WITH BATWING OPTIC ELDOLED 1061/M 100W, DRIVER

04.28.17

ISSUED FOR BID

04.14.17

PRELIMINARY TO ENGINEER

PROJECT

LIGHTING FIXTURE SCHEDULE Symbol

Lamp LED 3000K

LED 3000K

File SL4L_4_FLP_8 0CRI_30K_800 LMF.ies SL4L_4_FLP_8 0CRI_30K_600 LMF.ies SL4L_6_FLP_8 0CRI_30K_800 LMF.ies ICO_CYL_35_1 0_2AR_LSS_6 070D_MVOLT_ UGZ.ies ICO_CYL_35_1 0_2AR_LSS_6 070D_MVOLT_ UGZ.ies S4LID_8FT_CR D_1N35_2N35 BW_EZB_WH T.ies

Watts 0

Symbol

Label

Qty

Catalog Number

Description

L3BEM

S4LID 8FT CRD 1N30 2N30BW EZB WHT

SLOT 4 PENDANT MOUNT 8' (1) DIRECT NORMAL OUTPUT, 3000K BOARDS (2) INDIRECT NORMAL OUTPUT 3500K, BOARDS WITH BATWING OPTIC ELDOLED 1061/M 100W, DRIVER

Lamp LED 3000K

S4LID_8FT_CR D_1N35_2N35 BW_EZB_WH T.ies

Watts 99.2

STL4 30L EZ1 LP830

STL4 4' 3000 NOMINAL LUMENS 3000K

LED 3000K

STL4_30L_EZ1 _LP830.ies

L7B

STL4 40L EZ1 LP830

STL4 4' 4000 NOMINAL LUMENS 3000K

LED 3000K

STL4_40L_EZ1 _LP830.ies

L7C

STL2 20L EZ1 LP830

STL2 2' 2000 NOMINAL LUMENS 3000K

LED 3000K

ICO SQ 30/12 4AR INCITO 4" SQUARE 50D 120 DOWNLIGHT NICHIA 3000K, 1250 LUMEN

LED 3000K

L10

WSL-104-48-10030K

48'' Winline 104 with Nichia 757 LEDs and 100 degree optic.

L10A

WSL-104-24-10030K

24'' Winline 104 with Nichia 757 LEDs and 100 degree optic.

Label

Qty

Catalog Number

Description

Lamp

L11

ICO 30/15 4 AR 65D 120

INCITO 4" DOWNLIGHT 3000K 1500 LUMENS 65 DEGREE BEAM

LED 3000K

ICO_35_15_4_ AR_65D_120.i es

L11EM

ICO 30/15 4 AR 65D 120

INCITO 4" DOWNLIGHT 3000K 1500 LUMENS 65 DEGREE BEAM

LED 3000K

ICO_35_15_4_ AR_65D_120.i es

22.53

S4LWI_4FT_2 H35AS_EZB_ WHT.ies

L14A

Symbol

L13

L7A

13.72

File

STL2_20L_EZ1 _LP830.ies

ICO_SQ_35_1 2_4AR_50D_1 20.ies

LED 3000K

WSL-104-48100-30K.ies

LED 3000K

WSL-104-2410035K(PRORATE D).ies

L14B

L14C

S4LWI 4FT SLOT 4 PENDANT 2H30AS EZB WHT MOUNT 4' (2) INDIRECT HIGH, OUTPUT 3000K BOARDS WITH HALF BATWING OPTIC, ELDOLED 561/M 50 W DRIVER C5518.LED-35FX- 18" DIA PENDANT XX LUMINAIRE WHITE REFL w/MATTE WHITE ACRYLIC DROP LENS C5526.LED-30FX- 26" DIA PENDANT XX LUMINAIRE WHITE REFL w/MATTE WHITE ACRYLIC DROP LENS 38" DIA PENDANT WHITE C5538-30FX-10UP REFL LUMINAIRE 56,1" DIA CLEAR POLYCARB PLUGS IN TOP w/MATTE WHITE ACRYLIC CONVEX BTM LENS

LED 3000K

File

Watts

Symbol

Label

Qty

L14D

L15

L15B LED 3000K

LED 3000K

18683.IES

Catalog Number

Description

C5548.LED-30FX- 48" DIA PENDANT XX LUMINAIRE WHITE REFLECTOR w/MATTE WHITE ACRYLIC CONVEX BTM LENS S4LID 4FT CRD 1H30 2N30BW EZB WHT

S4LID 4FT CRD 1N30 2H30BW EZB WHT

SLOT 4 PENDANT MOUNT 4FT (1) DIRECT HIGH OUTPUT 3000K BOARDS (2) INDIRECT NORMAL OUTPUT 3000K BOARDS WITH BATWING OPTIC ELDOLED 1061/M 100W DRIVER SLOT 4 PENDANT MOUNT 4FT (1) DIRECT NORMAL OUTPUT 3000K BOARDS (2) INDIERCT HIGH OUTPUT 3000K BOARDS WITH BATWING OPTIC ELDOLED 1061/M 100 W DRIVER

Lamp

File

LED 3000K

18694.IES

Watts 0

CANCER RESEARCH INSTITUTE 29 BROADWAY, 4TH FLOOR, NEW YORK, NY 10006

LED 3000K

S4LID_4FT_CR D_1H35_2N35 BW_EZB_WH T.ies

S4LID_4FT_CR D_1N35_2H35 BW_EZB_WH T.ies

SHEET TITLE

4TH FLOOR REFLECTED CEILING PLAN 01.17.2017 1505-16 KR

SEAL & SIGNATURE

HG AS NOTED LED 3000K

18690.IES

A-102.00 1505-16RC04-A-102.00

000

KEY NOTES 1

PLAN NOTES 1)

PROPOSED NEW ELECTRICAL TRENCH. REFER TO ENGINEERING DRAWINGS FOR ADDITIONAL INFORMATION.

ARCHITECT

ALL OUTLETS FOR WORKSTATIONS AND PRIVATE OFFICE FURNITURE (INCLUDING OVERHEAD CABINETS) TO BE VERIFIED AND CONFIRMED WITH ARCHITECT AND FURNITURE VENDOR IN THE FIELD.

NORTH

STD. MOUNTING HTS.

STORAGE

04-36

OPEN WORKSTATIONS

04-28

04-27C

HT TBD

LOUNGE

OFFICE

04-22

04-53

OFFICE

04-21

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

6" 6" 1'-6"

CORR.

04-37

4'-0"

ADA

04-38

3'-2"

MEN

6'-8"

MEP ENGINEER:

04-20

BAR

SERVICE ELEV. 9

04-51 ELEV. 4

PANTRY

04-50 A3 A4 GFI

OFFICE

GFI

ELEV. 3

ELEV. 7

04-49

HT TBD

C I N

N. STAIR OFFICE

04-19 WOMEN

CORRIDOR

04-39

C I N

CLOSET B

04-30B

OPEN BENCH WORKSTATIONS

ELEV. 2

04-52 OFFICE

S. STAIR

04-48

ELEVATOR LOBBY ELEV. 6

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

04-27

CLOSET A

04-30A

OPEN WORKSTATIONS

04-27A

04-27B

OFFICE

04-18

COUNTER

ELEV. 8

MEN

EXPEDITER:

ELEC. CL

BAR

04-29

OFFICE

04-23

CLIENT:

BOARD ROOM

WOMEN

04-31

CORRIDOR

04-30 OFFICE

CLOS.

CORR.

04-41

04-33

MECH

EXISTING (REFER TO MEP)

04-35 MEETING

04-34

04-24

A2 04-32 PANTRY

(REFER TO MEP)

OFFICE

E2 GFI

04-46 CORRIDOR

GFI

OFFICE

04-16

E5 COPY

STOR

04-44A CORR.

04-40

04-45

04-44

04-43

MECH EXISTING (REFER TO MEP)

COATS A

RECEPTION

04-01A

COATS B

04-01

04-44B

THE CONTRACTOR IS RESPONSIBLE FOR: CONFIRMING AND CORRELATING ALL QUANTITIES AND DIMENSIONS.

COPY

04-00

HT TBD

OFFICE

NOTICE

SERVER

04-46A

COATS A

04-17

04-26

C I N

ELEC. CLOS.

UP GFI

04-47

ELEV. 5

CORRIDOR

HT TBD

OFFICE

COUNTER

ELEV. 1

COATS A

04-35A

OPEN WORKSTATIONS

OFFICE

OPEN WORKSTATIONS

04-25A

04-15

04-25B

WAITING

OPEN WORKSTATIONS

04-25C HT TBD

HT TBD

04-25 CORRIDOR

E2 OFFICE

04-42

04-02

CONFERENCE

OFFICE

04-04

04-05

04-06

04-07

04-08

04-09

04-10

04-11

04-12

04-13

OFFICE

16'

SEE DRAWING A-004 FOR SYMBOL LEGEND AND NOTES.

EQUIPMENT SCHEDULE No.

04-03

OFFICE

ITEM

APPLIANCE SCHEDULE MFR

SIZE

MODEL

NOTES

No.

ITEM

MFR

MODEL

PRINTER

TBD

N/A

REFRIGERATOR

SUMMIT

FFBF287SSIM

ST. STL DOORS, FROST-FREE OPERATION, FACTORY-INSTALLED ICEMAKER, PROVIDE WATER CONNECTION

FLAT SCREEN TV

TBD

N/A

COFFEE MAKER

TBD

NEEDS WATER CONNECTION, OWNER FURNISHED, GC INSTALLED

COPIER

TBD

N/A

MICROWAVE

TBD

OWNER FURNISHED, GC INSTALLED

SCANNER

TBD

N/A

DISHWASHER

ZDT975SSJSS

MONOGRAM 24" FULLY INTEGRATED DISHWASHER

SERVER RACK

TBD

N/A

BLOCK: LOT: ZONE: MAP:

29 Broadway - 4th Floor NEW YORK, NY 10006 20 01 C5-5 12b

ISSUED FOR BID

04.14.17

PRELIMINARY TO ENGR.

29 BROADWAY, 4TH FLOOR, NEW YORK, NY 10006 SHEET TITLE

4TH FLOOR POWER AND SIGNAL PLAN TRINITY PL

04.28.17

CANCER RESEARCH INSTITUTE

NOTES LOCATION:

PROJECT

PLOT PLAN

WAY

01.17.2017 1505-16 KR

SEAL & SIGNATURE

BROAD

HT TBD

04-14

AREA OF WORK

HG AS NOTED

A-103.00 1505-16PS04-A-103.00

000

PAINT EXISTING CORE DOORS.

SEE DRAWING A-004 FOR SYMBOL LEGEND AND NOTES.

PLAN NOTES

KEY NOTES

ARCHITECT

PAINT ALL EXISTING DOORS TO REMAIN AND ADJUST HARDWARE.

NORTH

MEP ENGINEER:

MEN

04-38

ADA

04-37

WOMEN

CORR.

04-39

STORAGE

04-36

04-28

BAR

CORRIDOR

04-29

04-27

OPEN WORKSTATIONS

BOARD ROOM

04-27C

LOUNGE

04-31

04-53 BAR

04-51 DN

ELEV. 4

F: F-2 B: W: C: -

ELEC. CL

C I N

N. STAIR ELEV. 3

F: F-1 B: W: C: -

OFFICE

ELEV. 7

04-49 OPEN BENCH WORKSTATIONS

04-52

F: F-1 B: W: C: -

OFFICE

04-48

ELEVATOR LOBBY

ELEV. 2

S. STAIR

04-30A

WOMEN

CORRIDOR

04-35A F: F-1 B: W: C: -

OFFICE

04-47

ELEV. 5

C I N

ELEC. CLOS.

COATS A

04-44A 04-44 COATS B

F: F-2 B: W: C: -

F: F-1 B: W: C: -

04-27A

04-27B

04-33

04-32

MECH

PANTRY

F: F-1 B: W: C: -

OFFICE

04-19

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

F: F-1 B: W: C: -

OFFICE

04-18

CLIENT:

OFFICE

F: F-1 B: W: C: -

04-23 F: F-1 B: W: C: -

OFFICE

04-17 CORRIDOR

04-26 F: F-1 B: W: C: -

F: F-2 B: W: C: -

OFFICE

04-24 F: F-1 B: W: C: -

CORR.

F: B: W: C:

04-35

F: F-1 B: W: C: -

04-34 F: F-2 B: W: C: -

CLOS.

F: F-1 B: W: C: -

OPEN WORKSTATIONS

F: F-1 B: W: C: -

1 F: B: W: C:

OPEN WORKSTATIONS

F: F-1 B: W: C: -

F: F-2 B: W: C: -

04-30

COATS A

ELEV. 1

F: F-1 B: W: C: -

CLOSET A

ELEV. 6

F: F-1 B: W: C: -

CLOSET B

04-30B

F: F-1 B: W: C: -

04-20

EXPEDITER:

PANTRY

04-50

OFFICE

04-21

ELEV. 8

MEN

OFFICE

04-22

SERVICE ELEV. 9

OFFICE

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

OFFICE

04-16 NOTICE IT IS A VIOLATION OF THE LAW FOR ANY PERSON TO ALTER THESE DOCUMENTS IN ANY WAY. THIS DRAWING, PREPARED FOR THE SPECIFIC PROJECT INDICATED, IS AN INSTRUMENT OF SERVICE AND THE PROPERTY OF JANKO RASIC ARCHITECTS (JRA). INFRINGEMENTS OR ANY USE OF THIS DRAWING FOR ANY OTHER PROJECT IS PROHIBITED. ANY ALTERATION OR REPRODUCTION OF THIS DOCUMENT IS ALSO PROHIBITED WITHOUT WRITTEN CONSENT OF JRA.

F: F-2 B: W: C: -

F: F-1 B: W: C: -

04-00 RECEPTION

F: F-1 B: W: C: -

THE CONTRACTOR IS RESPONSIBLE FOR: CONFIRMING AND CORRELATING ALL QUANTITIES AND DIMENSIONS.

OFFICE

04-15

04-01

04-44B

WAITING F: F-1 B: W: C: -

OPEN WORKSTATIONS

04-25A

04-25B

04-25C

OFFICE

04-14 F: F-1 B: W: C: -

04-43

04-42

OFFICE

CONFERENCE

F: F-1 B: W: C: -

F: B: W: C:

F: F-1 B: W: C: -

04-46A

04-45

04-02

STOR

MECH

OFFICE

F: F-1 B: W: C: -

04-03

OFFICE

F: F-1 B: W: C: -

04-04

04-05

04-41

04-06

04-07

04-40

04-08

04-09

04-10

04-25

04-11

04-12

04-13

OFFICE

MEETING

OFFICE

COPY

OFFICE

CORRIDOR

OFFICE

16'

FINISH SCHEDULE CONTINUED

FINISH SCHEDULE

BASE B-1 B-2

RUBBER BASE

WALLS W-1 CT-1

PAINT

CEILING C-1 C-1

BACKSPLASH TILE 2"X8"

INTERFACE MANNINGTON

DARK BARK

FINISH 9179

NOTES

No. TRANSIT. T-1 T-2

MATERIAL

MANF.

COLOR

FINISH

CARPET TO CARPET (SEWN) RUBBER REDUCER STRIP

NOTES CARPET TO CARPET CARPET TO TILE

LOCATION: BLOCK: LOT: ZONE: MAP:

CANCER RESEARCH INSTITUTE

29 Broadway - 4th Floor NEW YORK, NY 10006 20 01 C5-5 12b

29 BROADWAY, 4TH FLOOR, NEW YORK, NY 10006

MISC. D-1 D-2 D-3 D-4 CORIAN

GLACIER WHITE

MATTE

CV-1 WS-1

SHEET TITLE

METAL

PAINT

CONVECTOR PAINT

4TH FLOOR FINISH PLAN WAY

CARPET VCT

COLOR

PAINT

01.17.2017 1505-16 KR

SEAL & SIGNATURE

BROAD

FLOOR F-1 F-2 F-3

MANF.

ISSUED FOR BID

PROJECT

PLOT PLAN

TRINITY PL

No. MATERIAL

04.28.17

HG AS NOTED

MILLWORK SS-1 GL-1 PL-1 WD-2

COUNTERTOP 1/2" TEMPERED GLASS (CLEAR) PLASTIC LAMINATE CLEAR BIRCH (CABINET INTERIORS)

CORIAN

GLACIER WHITE

MATTE

AREA OF WORK

A-104.00 1505-16FN04-A-104

000

ARCHITECT

1/2" THK. TEMPERED GLASS ON TOP AND BOT. METAL CHANNELS, WITH 3M DISTRACTION FILM

NEW HOLLOW METAL FRAME

MEP ENGINEER: PROVIDE INSULATION, IF APPLICABLE. SEE PARTITION TYPES

RELOCATED EXISTING SALVAGED STAINED WOOD DOORS WITH SALVAGED HARDWARE, ON NEW HOLLOW METAL FRAME

3 A-201 TYP.

R 5 A-201

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

PROVIDE BLOCKING AS REQUIRED

4 A-201

TYP.

EXPEDITER:

1'-0" GWB

1'-4" GWB

1'-0" GWB

1'-4" GWB

R = SALVAGED DOOR

TYPICAL CORRIDOR ELEVATION - BASE BID - GLASS/CHANNEL, SALVAGED STAINED WOOD DOORS SCALE: 1/2"=1'-0" NEW HOLLOW METAL FRAME, SALVAGED DOOR HARDWARE

OFFICE

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

CORRIDOR

CEILING AS SCHEDULED SHADOW MOLDING 1 1/2" ALUM. TOP "C" CHANNEL TO RECEIVE GLASS

CLIENT:

3M DISTRACTION FILM

1/2" THK. TEMPERED GLASS WITH 3M DISTRACTION FILM STAINED WOOD DOOR

TOP OF GLASS DETAIL SCALE: 6"=1'-0"

NOTICE

GL WD

IT IS A VIOLATION OF THE LAW FOR ANY PERSON TO ALTER THESE DOCUMENTS IN ANY WAY. THIS DRAWING, PREPARED FOR THE SPECIFIC PROJECT INDICATED, IS AN INSTRUMENT OF SERVICE AND THE PROPERTY OF JANKO RASIC ARCHITECTS (JRA). INFRINGEMENTS OR ANY USE OF THIS DRAWING FOR ANY OTHER PROJECT IS PROHIBITED. ANY ALTERATION OR REPRODUCTION OF THIS DOCUMENT IS ALSO PROHIBITED WITHOUT WRITTEN CONSENT OF JRA. USE OF THIS FILE INCLUDING MODIFICATIONS IS AT THE SOLE RISK AND LIABILITY OF THE USER. THE USER SHALL TO THE FULLEST EXTENT THE LAW HOLD JRA HARMLESS FROM ANY CLAIMS, LIABILITIES, DAMAGES, LOSSES, JUDGMENTS, COST AND EXPENSES INCLUDING LEGAL FEES THAT MAY BE INCURRED BY JRA AS A RESULT OF ANY AND ALL USE OF THE CAD DATA, INCLUDING AND NOT LIMITED TO, ANY ALTERATIONS, MODIFICATIONS, DEVIATIONS FROM OR ADDITIONS TO THE DRAWINGS.

THE CONTRACTOR IS RESPONSIBLE FOR: CONFIRMING AND CORRELATING ALL QUANTITIES AND DIMENSIONS.

1/2" THK. TEMPERED GLASS WITH 3M DISTRACTION FILM

STAINED WOOD DOOR

1/2" ST. STL BOTTOM "C" CHANNEL. PROVIDE RUBBER SEALANT

FINISH FLOOR

TYPICAL CORRIDOR ELEVATION - (ALTERNATE - DIRTT SYSTEM - OFFICE FRONT SYSTEM) SCALE: 1/2"=1'-0" WOOD STAINED DOORS

BOTTOM OF GLASS DETAIL SCALE: 6"=1'-0"

PROVIDE INSULATION, IF APPLICABLE. SEE PARTITION TYPES

1/8" BEAD CLEAR SILICONE SEALANT 1

04.28.17

ISSUED FOR BID

PROJECT

CANCER RESEARCH INSTITUTE 29 BROADWAY, 4TH FLOOR, NEW YORK, NY 10006 SHEET TITLE 1/2" THK. TEMPERED GLASS WITH 3M DISTRACTION FILM

4TH FLOOR CORRIDOR ELEVATIONS

PROVIDE BLOCKING AS REQUIRED 01.17.2017 1505-16 KR

SEAL & SIGNATURE

GLASS TO GWB WALL DETAIL SCALE: 6"=1'-0"

HG AS NOTED

A-201.00 1505-16IE04-A-201.00

000

ARCHITECT

MEP ENGINEER:

7'-3" 3'-0"

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

2'-1"

10'-2"

EXPEDITER:

7'-8"

2'-6"

A2 COFFEMAKER

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

5 A-202 3 A-202

A3 MW ABOVE

2 A-202

COFFEMAKER

A1 REFRIGERATOR

CLIENT:

SINK

2'-1"

A3 MW ABOVE

A4 DISHWASHER

4'-9"

10'-0"

SINK

A4 DISHWASHER

2'-1"

A1 REFRIGERATOR

NOTICE

PANTRY A PLAN

2'-6"

SCALE: 1/2"=1'-0"

PANTRY B PLAN

SCALE: 1/2"=1'-0"

THE CONTRACTOR IS RESPONSIBLE FOR: CONFIRMING AND CORRELATING ALL QUANTITIES AND DIMENSIONS.

3 A-501

4 A-501

6 A-501

3 A-501

DEDICATED OUTLET

4 A-501

6 A-501

DEDICATED OUTLET

2'-6"

COFFEEMAKER

GFI

2'-0"

GFI GFI

A1 REF

DEDICATED OUTLET

SINK

DEDICATED OUTLET

2'-10"

3'-0"

SINK

10"

DEDICATED OUTLET

2'-10"

3'-0"

A1 REF

GFI 10"

10"

2'-0"

MW A3

DEDICATED OUTLET

04.28.17

ISSUED FOR BID

3'-0"

COFFEEMAKER

GFI

DEDICATED OUTLET

MW A3

2'-0"

DEDICATED OUTLET

2'-10"

2'-6"

1'-4"

4 A-501

18"

PROJECT

5 A-501

PANTRY A ELEVATION SCALE: 1/2"=1'-0"

5 A-501

PANTRY A ELEVATION SCALE: 1/2"=1'-0"

7 A-501

5 A-501

PANTRY B ELEVATION

7 A-501

CANCER RESEARCH INSTITUTE 29 BROADWAY, 4TH FLOOR, NEW YORK, NY 10006

SCALE: 1/2"=1'-0"

SHEET TITLE

4TH FLOOR PANTRY PLANS AND ELEVATIONS 01.17.2017 1505-16 KR

SEAL & SIGNATURE

HG AS NOTED

A-202.00 1505-16IE04-A-202.00

000

ARCHITECT

ALTERNATE EXISTING SLAB

EXISTING SLAB

INTUMESCENT SEALANT, TOP & BOTTOM, TYP. (SEE NOTE AT 1A)

SEALANT, TOP & BOTTOM, TYP.

SOUND ATTENUATION BLANKET

UNDERSIDE OF SLAB

SEE PARTITION 3A; GWB CONTINIOUS TO SLAB, NO DROP CEILING, OR ASOCIATED COMPONETS

3 A-201

BRACE AS REQ'D 221" 20 GA STL STUDS 16" O.C.

MEP ENGINEER: 6"

3 5/8" 20 GA STL STUDS 16" O.C.

CEILING AS SCHEDULED SPECIFIED CEILING, IF APPLICABLE

SPECIFIED CEILING, IF APPLICABLE CORRIDOR

2 1/2" METAL STUDS AT 16" O.C. W/ ONE (1) LAYER 5/8" GWB ON EACH SIDE FROM SLAB TO SLAB

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

SPECIFIED CEILING CEILING AS SCHEDULED

CEILING AS SCHEDULED SHADOW MOULDING, TYP

OVERHEAD FINISH GRADE WOOD BLOCKING, PAINTED

OFFICE

2 1/2" METAL STUDS AT 16" O.C. W/ ONE (1) LAYER 5/8" GWB ON EACH SIDE FROM SLAB TO SLAB

CORRIDOR

GWB SOFFIT

ROOM

2 1/2" METAL STUDS AT 16" O.C. W/ ONE (1) LAYER 5/8" GWB ON EACH SIDE FROM SLAB TO SLAB

SHADOW MOULDING, TYP OFFICE FRONT 1/2" TEMPERED GLASS CORRIDOR ALIGN

SPECIFIED BASE (SEE FINISH PLAN)

FINISHED FLOOR

1 HR FIRE RATED - INTUMESCENT SEALANT, WITH INSULATION

SCALE:1 1/2" = 1'-0"

SPECIFIED BASE (SEE FINISH PLAN) FINISHED FLOOR

FLOORING AS SCHEDULED

OFFICE PARTITION

PARTITION TYPE

SCALE:1 1/2" = 1'-0"

FULL HEIGHT, NON-RATED CAULKING SEALANT

PROVIDE FLASH PATCHING (WHERE REQUIRED)

LINE OF FINISH WOOD FLOOR (CARPET - ALTERNATE)

ACOUSTIC PARTITION

PARTITION TYPE

4 A-201

EXPEDITER:

OFFICE

SCALE:1 1/2"=1'-0"

OFFICE PARTITION (ALTERNATE)

PARTITION TYPE

SCALE:1 1/2" = 1'-0" OFFICE PARTITION CONTINUOUS GWB, BOTH SIDES TO SLAB

SCALE:1 1/2"=1'-0"

NON-RATED

PARTITION TYPE (DIRTT SYSTEM) SCALE:1 1/2" = 1'-0"

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

STANDARD / TYPICAL PARTITION

PARTITION TYPE

SCALE:1 1/2" = 1'-0"

OFFICE PARTITION (ALTERNATE) CONTINUOUS GWB, BOTH SIDES TO SLAB

CLIENT:

SCALE:1 1/2"=1'-0"

2'-0" EXISTING SLAB CONT. BEAD OF ACOUSTICAL SEALANT EA. SIDE

PROVIDE WOOD BLOCKING AS REQUIRED

2"X2" WOOD BLOCKING

WD2

5/8" THK. GWB EACH SIDE. USE GREENBOARD IN WET LOCATIONS

ARCHITECTURAL GLAZING TAPE BETWEEN GLASS PANES AS REQ'D. EXISTING WINDOW FRAME

2"X2" WOOD STUD WITH 1 LAYER OF 3" THK. ROXUL SAFE AND SOUND INSULATION

VALANCE

ALIGN

CONTINUOUS BEAD OF ACOUSTICAL SEALANT EA. SIDE, TYP.

FINISHED FLOOR AS SCHEDULED

MANUAL ROLL-UP BLIND FULL SIZE REFRIGERATOR

BOTTOM TRACK

REF

INTERIOR NON-RATED PARTITION POCKET DOOR WALL

FURRING PARTITION

PARTITION TYPE

SCALE:1 1/2" = 1'-0"

GLASS TO WALL DETAIL

SCALE: 1 1/2"=1'-0"

WINDOW POCKET DETAIL

SCALE: 1 1/2"=1'-0"

REFRIGERATOR CABINET DETAIL SCALE: 1 1/2"=1'-0"

WITH INSULATION GWB PARTITION

SCALE:1 1/2"=1'-0"

1-1/2"

SS-1

PL1

3/4" THK. PLYWOOD ADJUSTABLE SHELF ON STAINLESS STLEEL PINS

A3 MICROWAVE (REFER TO APPLIANCE SCHEDULE A-103) GC TO VIF DIMENSIONS. COORDINATE WITH ARCHITECT AND MILLWORKER

WD2

3/8" THK. PLYWOOD BACK PANEL WD-2 FINISH

CONCEALED SPRING HINGES "STANLEY"

UNDERCABINET LED LIGHTING SPECIFIED BASE SPECIFIED FLOOR COVERING

1'-2"

2'-1"

UPPER CABINET DETAIL SCALE: 1 1/2"=1'-0"

BASE CABINET W/ DRAWER & SHELF DETAIL SCALE: 1 1/2"=1'-0"

PANTRY SINK & FAUCET SEE PLUMBING SCHEDULE FOR INFORMATION A-101

PL1 PROVIDE HANDLES TO REMOVE PANEL 3/4" THICK PLYWOOD REMOVABLE ACCESS PANEL

MW CABINET DETAIL @ PANTRY SCALE: 1 1/2"=1'-0"

4TH FLOOR CONSTRUCTION PLAN 01.17.2017 1505-16 KR

SEAL & SIGNATURE 5"

SPECIFIED BASE SPECIFIED FLOOR COVERING

2'-1

1'-2"

2'-10"

SHEET TITLE 2'-0 3/4"

VERIFY

MICROWAVE SEE APPLIANCE SCHEDULE FOR INFO, GC TO VIF OPENING DIMENSIONS

29 BROADWAY, 4TH FLOOR, NEW YORK, NY 10006

HG AS NOTED

1'-11"

DRYWALL PARTITION

GC TO VIF ALL OPENINGS AND DIMENSIONS FOR ALL EQUIPMENT

3'-0"

CONCEALED SPRING HINGES "STANLEY"

WD2

PL1

PROVIDE OUTLET FOR MICROWAVE WHERE INDICATED ON ELEVATION

VERIFY

WD2

ISSUED FOR BID

CANCER RESEARCH INSTITUTE

PROVIDE WOOD BLOCKING AS REQ'D, TYP.

WOOD DRAWER ON "GRANT" SLIDING DRAWER HARDWARE

2'-6" VIF

3/4" THK PLYWOOD UNDERLAYMENT

PL1

04.28.17

PROJECT

CONCEALED SPRING HINGES "STANLEY"

PROVIDE WOOD BLOCKING AS REQUIRED

ADJUSTABLE SHELF

SS-1

ADJUSTABLE SHELF ON METAL SUPPORT PINS SET AT 11 2" O.C.

3/4" THK PLYWOOD UNDERLAYMENT

ADJUSTABLE SHELF

SS-1 SOLID SURFACE COUNTERTOP

1-1/2"

PROVIDE WOOD BLOCKING AS REQUIRED

EDGE OF ( SS-1 ) COUNTER BEYOND

PROVIDE WOOD BLOCKING AS REQUIRED

SOLID SURFACE COUNTERTOP

SIDE PANEL

TEMPERED GLASS

BASE AS SCHEDULED

DRYWALL PARTITION

(2) 2"X2" BOTTOM WOOD RUNNER

BASE AS SCHEDULED

THE CONTRACTOR IS RESPONSIBLE FOR: CONFIRMING AND CORRELATING ALL QUANTITIES AND DIMENSIONS.

PL1

2 1/2" METAL STUDS AT 16" O.C. W/ ONE (1) LAYER 5/8" GWB ON ONE (1) SIDE FROM FLOOR SLAB TO 6" ABOVE CEILING - NOTE: G.C. TO VERIFY STUD SIZES AS EXIST. WALL CONDITIONS VARY

CONCEALED SPRING HINGES "STANLEY"

REFER TO MANUFACTURE SPEC. FOR HEIGHT CLEARANCE

CEILING AS SCHEDULED, IF APPLICABLE SHADOW MOULDING

CABINET DETAIL @ PANTRY

A-501.00

SCALE: 1 1/2"=1'-0" 1505-16DT04-A-501.00

000

ARCHITECT

2-1/2" X 3/8" Ø EXPANSION BOLT

SLAB ABOVE

SLAB ABOVE 2-1/2" X 3/8" Ø EXPANSION BOLT 5/16" X 1" FLAT IRON HANGERS 4'6" O.C.

2-1/2" X 3/8" Ø EXPANSION BOLT

1-1/12" METAL CHANNELS @ 4'-0" O.C. MAX (.475 LBS./FT) CLIP

5/16" X 1" FLAT IRON RODS 4'-6" O.C.

MEP ENGINEER:

SLAB ABOVE

BRACE AS REQUIRED 5/16" X 1" FLAT IRON HANGERS 4'6" O.C.

"HAT" CHANNEL - 16" O.C. (MAX)

CEILING SUSPENSION SYSTEM

1-1 2" CHANNEL - 4'-6" O.C.(MAX)

ACOUSTIC TILE CEILING

5 8" GYPSUM BOARD CEILING

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

5/8" G.W.B. ON STUDS BRACE AS REQUIRED

5/8" GWB ON STUDS

SHADOW MOLDING

GWB CEILING

EXPEDITER: ACOUSTIC TILE CEILING

HUNG CEILING (TYP)

SCALE: 1-1/2"=1'-0"

7/8" HAT CHANNEL

VARIES

1 1/2" MTS

5/8" THICK GWB CEILING

SCALE: 1-1/2"=1'-0"

EXISTING SLAB CEILING

GWB CEILING (TYP)

GWB CEILING HEIGHT CHANGE SCALE: 1-1/2"=1'-0"

CORRIDOR CEILING HEIGHT CHANGE SCALE: 1-1/2"=1'-0"

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

VARIES

CLIENT:

CONDUIT CORNER BEAD VARIES

GWB SLAB CEILING LAMINATION SCALE: 1-1/2"=1'-0"

PRVIDE INSULATION, IF APPLICABLE. SEE PARTITION TYPES 2 1/2" METAL STUDS AT 16" O.C. W/ ONE (1) LAYER 5/8" GWB ON EACH SIDE CORNER BEAD ON EACH SIDE ACOUSTIC SEALANT AS REQ'D. ENCLOSE LOW PROFILE WALL STARTER ENCLOSE ZIPPER CONNECTOR

DASHED LINE INDICATES EDGE GWB SOFFIT ABOVE

PIVOT SWING GLASS DOOR ALUMINUM FRAME

04.28.17

ISSUED FOR BID

ENCLOSE FRAMELESS 3-WAY CLOSED POST

SWINGING DOOR & GWB WALL DETAIL (ALTERNATE - DIRTT SYSTEM OFFICE FRONT) SCALE: 1-1/2"=1'-0"

PROJECT

CANCER RESEARCH INSTITUTE 29 BROADWAY, 4TH FLOOR, NEW YORK, NY 10006 A.K.A. TRINITY PLACE SHEET TITLE

4TH FLOOR DETAILS 01.17.2017 1505-16 KR

SEAL & SIGNATURE

HG AS NOTED

A-502.00 1505-16DT04-A-502.00

000

Architect:

MEP Engineer: KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

CONSULTING ENGINEERS

Expediter: BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

BUILDING CODE CONSULTANTS

DOMINGO GONZALEZ ASSOCIATES 29 BROADWAY, 3RD FLOOR NEW YORK, NY 10006

Issue: ISSUE FOR BID 4.28.17

SHEET TITLE

COVER SHEET SEAL & SIGNATURE

04.28.2017 1505-12 KR HG NTS

T-001.00 1505-12CV03-TS-001.00

013

ABBREVIATIONS A A/C ACCES ACOUS ACT ADJ ADJUST AFF AL ALT ANNUNC ANOD APPL APPROX ARCH AUTO AVG

NYC DEPARTMENT OF BUILDINGS - GENERAL NOTES E E ELAST ELEC ELEV EMBED ENGR ENTR EQ EQUIP EWC EX/EXIST EXP JT EXPS EXT

B BDRM BLDG BOLLD BD BLKG BO BOH BRDLM BRZ BU

F FA FAB FD FE FE&C FHC FIN FLDG FPLC FR FRMG FXD FXTR FLR FLUOR FURN FWC

BEDROOM BUILDING BOLLARD BOARD BLOCKING BOTTOM OF BACK OF HOUSE BROADLOOM BRONZE BUILT UP

C CAB CPT CEM CER CLG CLR COATG COILG COL CONC CONSTR CONT CONTR COORD COV CMU

CABINET CARPET CEMENT (ITIOUS) CERAMIC CEILING CLEAR COATING COILING COLUMN CONCRETE CONSTRUCTION CONTINUOUS (ATION) CONTRACT (OR) COORDINATE COVER CONCRETE MASONRY UNIT

D DBL DEPT DET/DTL DF DIA DIFF DIM DISP DIV DN DR DSCON DWG DWR

HEAD HARDWOOD HARDWARE HOLLOW METAL HORIZONTAL HEIGHT HEATING, VENTILATING, AND AIR CONDITIONING

I INFO INSTRUM INSUL INTLK INT INFILTR

INFORMATION INSTRUMENTAL INSULATION INTERLOCK(ING) INTERIOR INFILTRATION

J JAN

LAVATORY POUND/POUNDS LANDLORD LIGHT LEVELING LOUVER

M MAX MFD MFR MECH MET/MTL MEMB MEZZ MIN MISC MLWK MOIST MOT MR MRB MRF MRT MTD

GAUGE GLASS FIBER GF REINFORCED CONCRETE GF REINFORCED GYPSUM GF REINFORCED PLASTER GLASS GRAD (E) (ING) GYPSUM

H HD HDWD HDWE HM HORIZ HT HVAC

KITCHEN

L LAV LB/LBS LL LT LVLG LVR

G GA GF GFRC GFRG GFRP GL GR GWB/GYP

DOUBLE DEPARTMENT DETAIL DRINKING FOUNTAIN DIAMETER DIFFUSER DIMENSION DISPENSER DIVISION DOWN DOOR DISCONNECT DRAWING DRAWER

K KIT

EXISTING ELASTOMETRIC ELECTRIC (AL) ELEVATION EMBEDD (ED) (ING) ENGINEER (ED) ENTRANCE EQUAL EQUIPMENT ELECTRIC WATER COOLER EXISTING EXPANSION JOINT EXPOSED EXTERIOR

MAXIMUM MANUFACTURED MANUFACTURER MECHANICAL METAL MEMBRANE MEZZANINE MINIMUM MISCELLANEOUS MILLWORK MOISTURE MOTOR (IZED) MARBLE MARBLE BASE MARBLE FLOOR MARBLE THRESHOLD MOUNTED

N NIC NO NTS

NOT IN CONTRACT NUMBER NOT TO SCALE

O OC ORNA OVFL OVHD OPNG OPR

ON CENTER ORNAMENTAL OVERFLOW OVERHEAD OPENINGS OPERABLE

P PB PT PTN PEDTR PBD PNL POLYST PORT PREFIN PREFAB PL/PLAM PLAS PLSTC PLYWD PMET PNL PRTECN PSS

R R RB RBR RCP RDR RECES RECPT

RELOCATE RUBBER BASE RUBBER REFLECTED CEILING PLAN READER RECESSED RECEPTACLE

S SCR SECT SECUR SF SGL SHORG SIM SS SST ST STD STL STRFR STRUCT SURF SUSP SYS

SCRIBE SECTION SECURITY SQUARE FEET SINGLE SHORING SIMILAR SIMULATED STONE STAINLESS STEEL STONE STANDARD STEEL STOREFRONT STRUCTURE/STRUCTURAL SURFACE SUSPENDED SYSTEMS

T TBD TEL THK TLT TO TRAF TRANS TRTD T&G TYP

TO BE DETERMINED TELEPHONE THICK TOILET TOP OF TRAFFIC TRANSPARENT TREATED TONGUE AND GROOVE TYPICAL

NOTES

U UNDRLAY UTIL UON

UNDERLAYMENT UTILITY UNLESS OTHERWISE NOTED

V VB VCT VEH VERT VIF VWC

VINYL BASE VINYL COMPOSITION TILE VEHICLE VERTICAL VERIFY IN FIELD VINYL WALLCOVERING

W W/ WD WDC WDW WH W/O WT WTRPRF

2. 3. 4. 5. 6.

WITH WOOD WINDOW CASING WINDOW WINDOW HEAD WITHOUT WEIGHT WATERPROOFING

JANITOR

(a) DETAIL

(b) HINGED DOOR

(d) FOLDING DOOR

18" MIN, 24 PREFERRED

(e) MAXIMUM DOORWAY DEPTH

CLEAR DOORWAY WIDTH AND DEPTH

Y X

NOTE: X=12" MIN IF DOOR HAS BOTH A LATCH AND A CLOSER

48" MIN

PUSH SIDE

54" MIN 48" MIN

Y=42" MIN

Y=48" MIN

Y=42" MIN

PUSH SIDE

X=24" MIN

PULL SIDE

(a) FRONT APPROACHES SWINGING DOORS

42" MIN

54" MIN

NOTE: X=36" MIN IF Y=60" X=42" MIN IF Y=54"

24" MIN

42" MIN

32" MIN CLEAR

48" MIN

32" MIN CLEAR

60" MIN

32" MIN CLEAR

PULL SIDE

24" MIN

32" MIN CLEAR

PUSH SIDE

PULL SIDE

32" MIN CLEAR

48" MIN

Y=48" MIN IF DOOR HAS 4' A LATCH8'AND A BOTH CLOSER

NOTE: Y=54" MINIMUN IF DOOR HAS CLOSER.

16'

X=48" MIN IF DOOR HAS A CLOSER

(d) FRONT APPROACHSLIDING AND FOLDING DOORS

(e) SLIDE SIDE APPROACHSLIDING AND FOLDING DOORS

(f) LATCH SIDE APPROACHSLIDING AND FOLDING DOORS

(b) HINGE SIDE APPROACHES - SWINGING DOORS

DRAWING INDEX

SPECIAL INSPECTIONS

ARCHITECTURAL

T-001.00 A-001.00 A-002.00 A-003.00 A-004.00 A-101.00 A-102.00 A-103.00 A-104.00 A-201.00 A-501.00 A-502.00 A-601.00

COVER SHEET GENERAL NOTES GENERAL NOTES GENERAL NOTES GENERAL NOTES CONSTRUCTION PLAN REFLECTED CEILING PLAN POWER AND SIGNAL PLAN FINISH PLAN INTERIOR ELEVATIONS DETAILS DETAILS DOOR SCHEDULE

ARCHITECT

MEP ENGINEER:

ENGINEERING TO FOLLOW

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

CONSULTING ENGINEERS EXPEDITER:

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

BUILDING CODE CONSULTANTS

CLIENT:

ENERGY CODE PROGRESS INSPECTION

ADA INFORMATION

NYC DEPARTMENT OF BUILDINGS - LIST OF INSPECTIONS

G.C. NOTE

APPLICABLE CODES N.Y.C. BUILDING CODE: 1968 N.Y.C. BUILDING CODE N.Y.C. PLUMBING CODE: 2014 INCLUDING LATEST UPDATES N.Y.C. MECHANICAL CODE: 2014 INCLUDING LATEST UPDATES N.Y.C. FUEL GAS CODE: 2014 INCLUDING LATEST UPDATES N.Y.C. ELECTRICAL CODE: N.E.C. 2011 INCLUDING LATEST UPDATES N.Y.C. FIRE CODE: 2014 N.Y.C. FIRE CODE ACCESSIBILITY: 2014 N.Y.C. BLDG. CODE, ANSI A117.1-2009 ED AND 2010 A.D.A. INCLUDING LATEST UPDATES NEW YORK CITY ENERGY CONSERVATION CODE; 2016 INCLUDING LATEST UPDATES. 1

04.28.2017

ISSUE FOR BID

TWO HINGED DOORS IN SERIES

PROJECT 60" MIN

(a) BACK WALL

(b) SIDE WALL

GRAB BARS AT WATER CLOSETS

19" MAX

29 BROADWAY, 3RD FLOOR, NEW YORK, NY 10006

48" MIN

24" MAX

CLEAR FLOOR SPACE AT LAVATORIES

DEPTH

(b) CLEAR FLOOR SPACE

LAVATORY CLEARANCES

ADA WATER CLOSET CLEARANCES

DOMINGO GONZALEZ ASSOCIATES

NOT TO EXCEED FOUNTAIN DEPTH

48" MIN

CLEAR FLOOR SPACE

8" MIN 6" MAX KNEE 17" MIN TOE CLEARANCE CLEARANCE

(a) 36"x36" STALL

30" MIN

40" MAX

34" MAX

9" MIN

29" MIN

CLEAR FLOOR SPACE

27" MIN

30" MIN

17" MIN

60" MIN FLOOR MTD. TOILET

LAV.

56" MIN WALL MTD TOILET

42" MIN

19" MIN

TOP OF SEAT 17" - 19"

33" - 36"

12"

17"-19" MIN

18" MIN.

54" MIN

33" - 36"

36" MIN 36" MIN 12" MIN 12" MIN

48" MIN

16" MIN

48" MIN

TOILET PAPER DISPENSER 39"-41"

(d) BUILT-IN FOUNTAIN OR COOLER

SHEET TITLE

3RD FLOOR GENERAL NOTES

DRINKING FOUNTAINS AND WATER COOLERS

(b) T-SHAPED SPACE FOR 180Â° TURNS WHEELCHAIR TURNING SPACE

BACK

18"

04.28.2017 1505-12 KR

SEAT WALL

BACK

48" MAX.

SEAL & SIGNATURE 33"-36" 38" MAX.

36" MIN

CONTROL WALL

CONTROL AREA

18"

33"-36"

CONTROL WALL

SEAT WALL

48" MAX.

33"-36" SIDE

60" MIN (a) 30" x 60" STALL

33"-36" 38" MAX.

30" MIN

CONTROL AREA

12" MIN

18" MIN.

(a) 60 " DIAMETER SPACE

LAV.

18"

36" MIN

CONTROL WALL 36" MIN

60" MIN

60" MIN 60" MIN

36" MIN

12" MIN

60" MIN

HG AS NOTED

CONTROL WALL

42" MIN (a) 30" x 60" STALL

(a) 36"x36" STALL

(a) 36" X 36" STALL

A-001.00 1505-12GN03-A-001.00

ARCHITECT

DIVISION 1 - GENERAL REQUIREMENTS COORDINATION cont'd

DIVISION 6 - WOODWORK, PLASTIC, & COMPOSITES

DIVISION 8 - OPENINGS (DOORS & WINDOWS)

GENERAL NOTES FOR ALL WOODWORK, PLASTIC & COMPOSITES:

GENERAL NOTES FOR ALL OPENINGS:

B. C.

E. F.

DIVISION 2 - SITE CONSTRUCTION NOT IN USE

NOT IN USE

DIVISION 4 - MASONRY

NOT IN USE

DIVISION 5 - METALS GENERAL NOTES FOR ALL METALS: A.

F. G.

N. O. P.

T. U.

DIVISION 7 - THERMAL & MOISTURE PROTECTION GENERAL NOTES FOR ALL THERMAL & MOISTURE PROTECTION: A.

D. E.

F. G.

DOORS AND FRAMES

MEP ENGINEER:

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

CONSULTING ENGINEERS EXPEDITER:

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

BUILDING CODE CONSULTANTS

CLIENT:

04.28.2017

ISSUE FOR BID

PROJECT

DOMINGO GONZALEZ ASSOCIATES 29 BROADWAY, 3RD FLOOR, NEW YORK, NY 10006 SHEET TITLE

3RD FLOOR GENERAL NOTES 04.28.2017 1505-12 KR

SEAL & SIGNATURE

HG AS NOTED

A-002.00 1505-12GN03-A-002.00

ARCHITECT

DIVISION 9 - FINISHES

DIVISION 9 - FINISHES cont'd

DIVISION 12 - FURNISHING

GENERAL NOTES FOR ALL FINISHES:

09.70.00 WALL FINISHES (INCLUDES ALL SUBDIVISIONS)

GENERAL NOTES FOR ALL SPECIALTIES:

09.90.00 PAINTING AND COATING

DIVISION 14 - CONVEYING SYSTEMS NOT IN USE

DIVISION 16 - ELECTRICAL GENERAL NOTES FOR ALL DEVICES AND SYSTEMS: A. ALL MATERIALS, PRODUCTS, AND METHODS TO BE DELIVERED, HANDLED, AND INSTALLED PER MFR'S SPECIFICATIONS, FREE OF DEFECT, AND SHALL COMPLY WITH APPLICABLE LOCAL LAWS AND BEST INDUSTRY PRACTICES AND WORKMANSHIP. DEFECTIVE PRODUCT & INSTALLATION SHALL BE REPLACED AT CONTRACTOR'S SOLE COST B. SUBMITTALS (PRODUCT DATA): B.1. SUBMIT MFR'S DATA SHEETS AND CATALOGUE CUTS FOR ALL ELECTRICAL EQUIPMENT INCLUDING BUT NOT LIMITED TO LIGHT FIXTURES, COVER PLATES, JRA TO SELECT ALL VISIBLE EQUIPMENT COLORS & FINISHES. C. SUBMITTALS (DRAWINGS): D. SUBMIT SHOP DRAWINGS SHOWING LOCATIONS, PLAN(S), SCHEDULES, ELEVATIONS, DETAILS. DRAWINGS MUST SHOW CEILING HEIGHTS AND HEIGHTS OF FIXTURES. E. GC TO VERIFY ALL DIMENSION AND CONDITIONS. NOTIFY JRA OF ANY DISCREPANCIES PRIOR TO WORK. COORDINATE LIGHT FIXTURES WITH AV EQUIPMENT, HVAC EQUIPMENT, STRUCTURAL WORK ETC... F. GC TO VERIFY FURNITURE FEED LOCATIONS WITH FURN VENDOR AND ARCHITECT PRIOR TO INSTALLATION G. CONTRACTOR TO FURNISH ALL LABOR AND ELECTRICAL , CONDUIT, WIRE , BOXES; MATERIALS TO COMPLETE ALL WORK SHOWN ON THE DRAWINGS INCLUDING BUT NOT LIMITED TO EQUIPMENT, INSULATION, LINERS, FASTENINGS, SUPPORTS, ATTACHMENTS, AND BLOCKING AS RECOMMENDED BY MFR. H. ALL SWITCH AND OUTLET COVER PLATES TO BE SCREWLESS. SPEC TO BE CRESTRON. SUBMIT SAMPLE TO JRA FOR APPROVAL. I. GC TO CAP ALL NON-ACTIVE OUTLETS AS PART OF CONTRACT J. COORDINATE ELECTRICAL REQUIREMENTS FOR ALL FURNITURE, SYSTEMS FURNITURE, CASEGOODS, MILLWORK, AND WOODWORK. K. DO NOT CUT OR ABRADE FINISHES WHICH CANNOT BE COMPLETELY RESTORED IN FIELD. L. AT COMPLETION OF THE PROJECT, REMOVE ALL PROTECTIVE COVERINGS AND CLEAN EXPOSED SURFACES. M. ALL WORK AND MATERIALS (INCLUDING INSTALLATION, MATERIAL & WORKMANSHIP WARRANTY) INCLUDED IN THE CONTRACT DOCUMENTS SHALL BE UNCONDITIONALLY GUARANTEED AGAINST DEFECTS IN MATERIALS AND WORKMANSHIP FOR THE PERIOD STIPULATED IN THE MFR'S SPECIFICATIONS OR FOR ONE YEAR, WHICHEVER IS LONGER. N. ALL LIGHTING FIXTURES (LUMINAIRES), REMOTE DRIVERS, CONTROLS (CRESTRON) CONTROL DRIVERS TO BE TENANT FURNISHED. O. CONTRACTORS TO ACCEPT DELIVERY OF ALL LIGHTING FIXTURES AND CONTROL EQUIPMENT AND COORDINATE STORAGE W BUILDER/OWNER. P. CONTRACTOR TO: COORDINATE ALL WIRING, CONTROL, INSTALLATION AND MOUNTING CONDITIONS; INSTALL ALL LIGHTING EQUIPMENT; INSTALL AND COMMISSION ALL LIGHTING CONTROL EQUIPMENT, DEVICES AND ACCESSORIES; Q. ALL IT/DATA (LOW-VOLTAGE) CABLING & NETWORK CONNECTIONS/OUTLETS TO BE INSTALLED BY TENANTS SUB CONTRACTOR. EC / GC TO COORDINATE REGARDING PENETRATIONS, CABLING RUNS & SEQUENCING OF WORK. .

MEP ENGINEER:

KM ENGINEERING, D.P.C. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 718.710.5406 F: 516.341.0716

CONSULTING ENGINEERS EXPEDITER:

BIG CITY EXPEDITING INC. 46 ELGIN RD. VALLEY STREAM, NY 11581 T: 516.341.0716

BUILDING CODE CONSULTANTS

CLIENT:

DIVISION 11 - EQUIPMENT NOT IN USE

04.28.2017

ISSUE FOR BID

PROJECT

DOMINGO GONZALEZ ASSOCIATES 29 BROADWAY, 3RD FLOOR, NEW YORK, NY 10006 SHEET TITLE

3RD FLOOR GENERAL NOTES SEAL & SIGNATURE

04.28.2017 1505-12 KR HG AS NOTED

GENERAL GRAPHIC SYMBOLS PRIVATE OFFICE

ROOM AREA NUMBER

02-26

KEY NOTE

DEMOLITION/CONSTRUCTION GRAPHIC GRAPHIC SYMBOLS

REFLECTED CEILING GRAPHIC SYMBOLS

POWER & SIGNAL GRAPHIC SYMBOLS

CEILING TYPE (EX= EXISTING, ACT= ACOUSTICAL TILE AND GRID, GB = GYPSUM BOARD 5/8" THICK)

EXISTING MATERIAL TO BE REMOVED

DUPLEX RECEPTACLE OUTLET @ 1'-4" A.F.F. *

2 4

ELEVATION NUMBER

A000.00

DRAWING NUMBER SECTION SYMBOL

1 A000.00

SECTION NUMBER DRAWING NUMBER

DETAIL SYMBOL AREA SHOWN IN DETAIL

EXISTING DOOR TO BE REMOVED

GFCI

CHANGE IN CEILING HEIGHT AND/OR MATERIAL

EXISTING WALL TO REMAIN

DUPLEX RECEPTACLE FOR COMPUTER POWER TELEPHONE JACK

EXISTING DOOR TO REMAIN SWITCH W

SCALE: 1/8"=1'-0"

CONTINUOUS PLUG STRIP

GYPSUM BOARD CEILING 5/8" THICK

SFT

SEPARATE DUPLEX OUTLET

START FULL TILE

REVISED AREA

PARTITION TYPE (SEE PARTITIONS DETAILS DRAWING A-500 FOR MORE INFORMATION)

CABLE TV OUTLET

CENTER LINE

DOOR NUMBER (SEE DOOR SCHEDULE FOR MORE INFORMATION)

INTERCOM

DISTANCE ABOVE FINISH FLOOR (AFF)

PLUMBING SYMBOL (SEE SCHEDULE FOR MORE INFORMATION)

CARD READER MAGNETIC LOCK KEY OVERRIDE

ALIGN WITH ESTABLISHED SURFACES

NEW MILLWORK. SUBMIT SAMPLES AND SHOP DRAWINGS FOR ARCHITECT'S REVIEW AND APPROVAL PRIOR TO FABRICATION. (SEE ELEVATIONS AND DETAILS FOR MORE INFORMATION)

APPLIANCE SYMBOL (SEE APPLIANCE SCHEDULE FOR MORE INFORMATION)

SEE LIGHTING SCHEDULE FOR ADDITIONAL LIGHT SYMBOLS REFLECTED CEILING PLAN NOTES

FINISH GRAPHIC SYMBOLS

TEL./ELEC. & FURN. PLAN NOTES 1. EQUIPMENT AND FURNITURE ARE NOT IN CONTRACT. (U.N.O.).

3. NOTIFY ARCHITECT OF ANY DISCREPANCIES PRIOR TO INSTALLATION.

ARCHITECT TO APPROVE CHALK LINE PARTITION LAYOUT BEFORE SECURING METAL TRACKS. NOTIFY ARCHITECT AT LEAST THREE (3) DAYS IN ADVANCE TO SCHEDULE LAYOUT INSPECTION.