LEGAL NOTICE NOTICE TO BIDDERS Sealed bids for RISING SUN PORT AUTHORITY HANGAR BUILDING, will be received by the City of Rising Sun until 1:00 p.m. Eastern Daylight Time on Thursday. November 15, 2012. Bids will be opened and read aloud by the OWNER immediately after the closing time for acceptance of bids. Bids delivered after this time will be retumed unopened. Bids shall be delivered to: Mike Northcutt, City of Rising Sun, 200 North Walnut Street, Rising Sun, IN 47040. A Pre-Bid Conference for the discussion of the work, the bidding requirements, and other important matters will be held on Thursday, November 1, 2012, at 10:00 am., Eastern Daylight Time. at the City of Rising Sun, 200 North Walnut Street, Rising Sun, IN 47040, Attendance is not mandatory. but encouraged. Copies of the Bidding Documents shall be ob tained, starting October 25, 2012. from the City of Rising Sunt 200 North Walnut Street, Rising Sun, IN 47040, upon payment of $75 per set, payable to the Rising Sun Port Authority (phone: 812-438-3324 and fax: 812-438-3561). Copies of the Bidding Docu ments may be examined at the City of Rising Sun, 200 North Walnut Street, Rising Sun. IN 47040 or Land Consultants, 314 Front Street, Lawrenceburg. Indiana 47025. All bids shall be per contract documents and be accompanied by a five percent Bid Bond. One hun dred percent performance and payment bonds will be required of the successful bidder. The Project consists of, but is not necessarily limited to, the following: construction of a 2,700 sf wood frame and block aircraft hangar building on a 0.5 acre lot on Front Street. The hangar building includes an office, water and electric ulilities. con crete driveway, grading and seeding, and installation of an oil/water seperator. Bidders shall assure that they have obtained complete Set of Contract Documents and shall assume the risk of any errors or omissions in bids prepared in reliance on incomplete sets of Contract Docu ments. All bids and proposals shall be properly and completely executed on the proposal fonns provided with the plans and specifications that will include the non-collusion affidavit as required by the State of Indiana. The bid envelope must be scaled and have the words "BID - RISING SUN PORT AUTHORITY HANGAR BUILDING". It is intended that actual construction of all work divisions shall be started as soon as practicable, and each bidder shall be prepared to enter promptly into a construction contract, furnish a performance bond, payment bond, proof of insurance, and begin work without delay in the event the award is made to him. No bidder may withdraw any bid or proposal within a period of sixty (60) days following the date set for receiving bids or proposals. The Rising Sun Port Authority reserves the right to hold any or all bids or proposals for a period of not more than sixty (60) days and said bids or proposal shall remain in full force and effect during said period. The Rising Sun Port Authority reserves the right to reject any or all bids. Or to waive any informalities and to accept the bid that it deems most favorable to the interest of the Rising Sun Port Authority after all bids have been examined. The WORK shall be substantially completed within 90 calendar days, and will be completed and ready for final payment within 120 calendar days from the date when the Contract Time starts. Bidders shall complete Standard Questionnaire Form 96 and include it with their bid. including the non-collusion affidavit. Bidders shall ensure all employees and applicants for employment are not discriminated against because of their racet creed. color, sex, or national origin. An Affirmative Action Statement shall be submitted with the bid. The Rising Sun Port Authority will fund this WORK. Funds have been budgeted for this project. Contractors and subcontractors are required to pay not less than the Common Construction Wage Rates established by the Indiana Department of Labor and induded in the project specification if the project cost exceeds $250,000. Failure to execute a contract and to furnish a Petformance and Payment Bond as hereinafter set out will be cause for forfeiture to the Owner of the amount of money represented by the certified check or Bidder's Bond, as and for liquidated damages. The Owner reserves the right to reject any bid, or all bids, or to accept any bid or bids, or to make such combination of bids as may seem desirable, and to waive any and all informalities in the bidding. BY ORDER OF THE RISING SUN PORT AUTHORITY C-10-25-RSR-2t C-10-25-OCN-2t
NOTICE OF SHERIFFʼS SALE By virtue of a certified copy of a decree to me directed from the Clerk of Ohio Circuit Court of Ohio County, Indiana, in Cause No. 58C01-0903-MF-0011 wherein Chase Home Finance LLC was Plaintiff, and Harry E. Pryce, Janelle Pryce aka Janella Pryce and Rising Sun State Bank were Defendants, re quired me to make the sum as provided for in said Decree with interest and cost, I will expose at public sale to the highest bidder, on the 20th day of No vember, 2012, at the hour of 10:00 a m, or as soon thereafter as is possible, at 121 South Mulberry Street, Rising Sun, IN 47040, the fee simple of the whole body of Real Estate in Ohio County, Indiana. Fifty-six (56) feet off the North side of Lot number Four (4) in Able C. Pepper's Addition to the Town, now City, of Rising Sun, in said county and state, fronting on High Street and extending back to the alley. More commonly known as 112 S High St, Rising Sun, IN 47040-1117 Parcel No. 58-06-03-004-020.000-004 Together with rents, issues, income and profits thereof, said sale will be made without relief from valuation or appraisement laws. Eldon Fancher, Sheriff Cass Township The Sheriff's Department does not warrant the accuracy of the street address published herein. MARC J. ANCEL, Plaintiff Attorney Attorney # 23488-49 FEIWELL & HANNOY, P.C. 251 N. Illinois Street, Suite 1700 Indianapolis, IN 46204-1944 (317) 237-2727 NOTICE FEIWELL & HANNOY, P.C. IS A DEBT COLLECTOR. C-10-18-RSR-3t
k c e t! h C Ou It
NOTICE OF SHERIFF'S SALE By virtue of a certified copy of a decree to me directed from the Clerk of the Superior Court of Ohio County, Indiana, in Cause No. 58C01-1108-MF-0019, wherein Fifth Third Mortgage Company was Plaintiff, and Hasson N. Lowry a/k/a Hasson Najeeb Lowry and Linda Lowry a/k/a Linda K. Lowry, were the Defendants, requiring me to make the sum as provided for in said Decree with interest and costs, I will expose at public sale to the highest bidder, on the 22nd day of January, 2013, at 10:00 A.M. of said day, at the 123 S. Mulberry St., Rising Sun, IN 47040, the fee simple of the whole body of Real Estate in Ohio County, Indiana: Situated in the Northeast Quarter of Section 35, Township 4 North, Range 2 West and the Northwest Quarter of Section 36, Township 4 North, Range 2 West in Union Township, Ohio County, Indiana and being more particularly described as follows: Beginning at a 36 inch Hackberry Tree at the North west Corner of the Northwest Quarter of Section 36, T4N, R2W and the TRUE POINT OF BEGINNING of the property herein described; thence along the north line of said quarter, North 90° 00' 00" East, 498.53 feet to an existing railroad spike in Cappel Road, passing an existing iron rebar at 1.45 feet; thence leaving the north line of said quarter and along said road for the following seven (7) courses: South 2° 09' 27" West, 53.12 feet to a set mag nail; thence South 17° 42' 19" West, 62.67 feet to an existing railroad spike; thence South 31° 43' 09" West, 71.28 feet to an existing railroad spike; thence South 39° 59' 54" West, 147.92 feet to an existing railroad spike; thence South 30° 09' 36" West, 63.57 feet to an existing railroad spike; thence South 16° 46' 40" West, 56.99 feet to an existing railroad spike; thence South 4° 44' 39" West, 43.86 feet to an existing railroad spike at the northeast corner of a 21.231 acre tract, owned by Odis Davis and Melissa J. Davis as recorded in Deed Record 32, Page 298 of the Ohio County Recorder's Office; thence leaving said road and along the north line of said 21.231 acre tract for the following two (2) courses: South 83° 52' 04" West, 374.68 feet to an existing iron rebar, passing an existing iron rebar at 25.10 feet; thence North 82° 56' 17" West, 54.71 feet to a set iron rebar at the southeast corner of a 5.000 acre tract, owned by Odis Davis and Melissa J. Davis as recorded in Instrument No. 20030932 of the Ohio County Recorder's Office; thence leaving the north line of said 21.231 acre tract and along the east line of said 5.000 acre tract, North 0° 00' 00" East, 471.32 feet to a set iron rebar at the northeast corner of said 5.000 acre tract and the north line of the Northeast Quarter of Section 35, T4N, R2W; thence along the north line of said quarter, North 89° 10' 00" East, 133.95 feet to the point of beginning, passing a set iron rebar at 54.30 feet, containing 1.4612 acres of land, more or less, in Section 35, T4N, R2W, and 4.1310 acres of land, more or less, in Section 36, T4N, R2W, being a total of 5.5922 acres of land, more or less, and being subject to the legal right-of-way of Cappel Road and to any other easements or restrictions of record. 58-02-35-100-001.000-005 and commonly known as: 6455 Cappel Road, Aurora, IN 47001. Subject to all easements and restrictions of record not otherwise extinguished in the proceedings known as Cause # 58C01-1108-MF-0019 in the Superior Court of the County of Ohio Indiana, and subject to all real estate taxes, and assessments currently due, delinquent or which are to become a lien. Said sale will be made without relief from valuation or appraisement laws. If the sale is set aside for any reason, the Purchaser at the sale shall be entitled only to a return of the deposit paid. The Purchaser shalt have no further recourse against the Mortgagor, the Mortgagee, or the Mortgagee's Attorney. Eldon Fancher Ohio County Sheriff Union Township James L. Shoemaker (19562-49) S. Brent Potter (10900-49) Craig D. Doyle (4783-49) Rayanna A. Binder (24776-49) Christina M. Bruno (27334-49) Curt D. Hochbein (29284-29) Ryan T. Kiernan (29316-49) David M. Johnson (30-354-45) Evgeny G. Mogilevsky (27602-49) Doyle Legal Corporation, P.C. 41 E Washington Street, Suite 400 Indianapolis, IN 46204 Telephone (317) 264-5000 Facsimile (317) 264-5400 C-10-18-RSR-3t IN THE OHIO CIRCUIT COURT CAUSE NO. 58C01-1210-MF-0029 STATE OF INDIANA COUNTY OF OHIO U.S. BANK NATIONAL ASSOCIATION, a/k/a U.S. BANK N.A. PLAINTIFF VS. MARK A. LIND, et al DEFENDANTS SUMMONS BY PUBLICATION TO: Mellon Mortgage Company, whereabouts unknown: A foreclosure Complaint has been instituted against the real estate located at 6760 Poorhouse Hill, Rising Sun, Indiana, by the mortgagee before the Ohio Superior/Circuit Court, Cause No. 58C01-1210MF-0029 styled "U.S. Bank National Association, a/k/a U.S. Bank N.A. (Plaintiff) vs. Mark A. Lind, Rising Sun Ohio County Community School Corp., Secretary of Housing and Urban Development and Mellon Mortgage Company (Defendants)". YOU MUST RESPOND TO THE COMPLAINT WITHIN THIRTY (30) DAYS AFTER THE LAST NOTICE OF THE ACTION IS PUBLISHED AND IN CASE THE DEFENDANTS FAIL TO DO SO, JUDGMENT BY DE FAULT MAY BE ENTERED AGAINST THEM FOR THE RELIEF DEMANDED IN THE COMPLAINT, INCLUDING SALE OF THE REAL ESTATE. Septtimous Taylor Septtimous Taylor, II 4830 Towne Square Court Owensboro, KY 42301 IN Bar #18326-82 IN Bar #23999- 74 Attorneys for Plaintiff C-11-1-OCN-3t NOTICE OF SHERIFF'S SALE By virtue of a certified copy of a Decree to me directed from the clerk of Circuit Court of Ohio County, Indiana, in Cause No. 58C01-1005-MF-0012, wherein Bank of America, N.A. successor by merger to BAC Home Loans Servicing, LP fka Countrywide Home Loans Servicing, LP was Plaintiff, and David Hall a/k/a David John Hall was/were the Defendant(s), requiring me to take the sums as provided for in said Decree, with interest and costs, I will expose at public sale to the highest bidder, on the 12th day of February, 2013, at the following location and time: Ohio County Courthouse, 121 South Mulberry Street, Rising Sun, Indiana 47040, at 10:00 a.m. the fee simple of the whole body of the following described real estate located in Ohio County, Indiana. SITUATED IN OHIO COUNTY, INDIANA BEING PART OF THE SOUTHWEST QUARTER OF SEC TION 21, TOWNSHIP 4 NORTH, RANGE 3 WEST OF THE FIRST PRINCIPAL MERIDIAN LOCATED IN PIKE TOWNSHIP, OHIO COUNTY, STATE OF INDIANA, DESCRIBED AS FOLLOWS: COMMENCING AT THE NORTHWEST CORNER OF THE SOUTH WEST QUARTER OF SECTION 21, TOWNSHIP 4 NORTH, RANGE 3 WEST; THENCE SOUTH 88 DEGREES 40 MINUTES 28 SECONDS EAST ALONG THE EAST-WEST DIVISION LINE OF SAID SECTION 21, 1174.13 FEET TO A RE-BAR AND POINT OF BEGINNING; THENCE CONTINUING SOUTH 88 DE GREES 40 MINUTES 28 SECONDS EAST ALONG SAID DIVISION LINE, 307.11 FEET TO A RE-BAR; THENCE SOUTH 00 DEGREES 00 MINUTES 00 SECONDS EAST, 627.92 FEET TO THE CENTER OF ABERDEEN ROAD; THENCE ALONG THE CENTER LINE OF SAID ABERDEEN ROAD THE FOLLOWING FOUR COURSES; THENCE NORTH 56 DEGREES 46 MINUTES 32 SECONDS WEST, 96.73 FEET; THENCE NORTH 66 DEGREES 02 MINUTES 09 SECONDS WEST, 66.66 FEET; THENCE NORTH 86 DEGREES 02 MINUTES 39 SECONDS WEST, 75.53 FEET; THENCE SOUTH 78 DEGREES 55 MINUTES 02 SECONDS WEST, 91.55 FEET; THENCE NORTH 00 DEGREES 00 MINUTES 00 SECONDS EAST,
Countrywide Home Loans Servicing, LP was Plaintiff, and David Hall a/k/a David John Hall was/were the Defendant(s), requiring me to take the sums as provided for in said Decree, with interest and costs, I will expose at public sale to the highest bidder, on the 12th day of February, 2013, at the following location and time: Ohio County Courthouse, 121 South Mulberry Street, Rising Sun, Indiana 47040, at 10:00 a.m. the fee simple of the whole body of the following described real estate located in Ohio County, Indiana. SITUATED IN OHIO COUNTY, INDIANA BEING PART OF THE SOUTHWEST QUARTER OF SEC TION 21, TOWNSHIP 4 NORTH, RANGE 3 WEST OF THE FIRST PRINCIPAL MERIDIAN LOCATED IN PIKE TOWNSHIP, OHIO COUNTY, STATE OF INDIANA, DESCRIBED AS FOLLOWS: COMMENCING AT THE NORTHWEST CORNER OF THE SOUTH WEST QUARTER OF SECTION 21, TOWNSHIP 4 NORTH, RANGE 3 WEST; THENCE SOUTH 88 DEGREES 40 MINUTES 28 SECONDS EAST ALONG THE EAST-WEST DIVISION LINE OF SAID SECTION 21, 1174.13 FEET TO A RE-BAR AND POINT OF BEGINNING; THENCE CONTINUING SOUTH 88 DE GREES 40 MINUTES 28 SECONDS EAST ALONG SAID DIVISION LINE, 307.11 FEET TO A RE-BAR; THENCE SOUTH 00 DEGREES 00 MINUTES 00 SECONDS EAST, 627.92 FEET TO THE CENTER OF ABERDEEN ROAD; THENCE ALONG THE CENTER LINE OF SAID ABERDEEN ROAD THE FOLLOWING FOUR COURSES; THENCE NORTH 56 DEGREES 46 MINUTES 32 SECONDS WEST, 96.73 FEET; THENCE NORTH 66 DEGREES 02 MINUTES 09 SECONDS WEST, 66.66 FEET; THENCE NORTH 86 DEGREES 02 MINUTES 39 SECONDS WEST, 75.53 FEET; THENCE SOUTH 78 DEGREES 55 MINUTES 02 SECONDS WEST, 91.55 FEET; THENCE NORTH 00 DEGREES 00 MINUTES 00 SECONDS EAST, 567.33 FEET TO THE POINT OF BEGINNING. CONTAINS 4.007 ACRES AND IS PART OF THE LANDS OF GASTON D. COGDELL AND JENELL COGDELL (D.R. 14, P. 449) AND (D.R. 13, P. 446-447). SUB JECT TO ANY AND ALL EASEMENTS. SUBJECT TO THE PUBLIC RIGHT-OF-WAY OF ABERDEEN ROAD. TOGETHER WITH AND SUBJECT TO A 50 FOOT WIDE UTILITY EASEMENT, LOCATED AS ALREADY CONSTRUCTED OR AS WILL BE CON STRUCTED IN THE FUTURE, WITH THE RIGHT OF INGRESS AND EGRESS TO CONSTRUCT, MAIN TAIN, INSPECT, OPERATE, REPAIR, AND REPLACE UTILITIES, WHEN AND AS NEEDED. TOGETHER WITH AND SUBJECT TO EASEMENT NUMBER 4 FOR INGRESS, EGRESS AND UTILITIES, DE SCRIBED BELOW. TOGETHER WITH AND SUB JECT TO EASEMENT NUMBER 3 FOR INGRESS, EGRESS AND UTILITIES, DESCRIBED BELOW. THE OWNER OF ANY LOT WHO USES AN ACCESS EASEMENT FOR INGRESS AND EGRESS TO OR FROM A LOT SHALL SHARE EQUALLY IN THE MAINTENANCE OF SAID ACCESS EASEMENT. EASEMENT NUMBER 3: BEING PART OF THE SOUTHEAST QUARTER OF SECTION 20 AND PART OF THE SOUTHWEST QUARTER OF SECTION 21, TOWNSHIP 4 NORTH, RANGE 3 WEST OF THE FIRST PRINCIPAL MERIDIAN LOCATED IN PIKE TOWNSHIP, OHIO COUNTY, STATE OF INDIANA, AND BEING AN EASEMENT FOR INGRESS, EGRESS AND UTILITIES 50 FEET IN WIDTH, 25 FEET ON EACH SIDE OF A CENTERLINE DE SCRIBED AS FOLLOWS: COMMENCING AT THE NORTHWEST CORNER OF THE SOUTHWEST QUARTER OF SECTION 21, TOWNSHIP 4 NORTH, RANGE 3 WEST; THENCE NORTH 87 DEGREES 25 MINUTES 12 SECONDS WEST, 312.18 FEET TO A RE-BAR; THENCE SOUTH 00 DEGREES 00 MIN UTES 00 SECONDS EAST, 731.65 FEET TO THE CENTER OF ABERDEEN ROAD; THENCE NORTH 72 DEGREES 46 MINUTES 48 SECONDS WEST, 32.97 FEET TO THE POINT OF BEGINNING OF THE CENTERLINE OF AN EASEMENT FOR INGRESS, EGRESS AND UTILITIES; THENCE ALONG THE CENTERLINE OF SAID EASEMENT THE FOLLOWING 22 COURSES; THENCE NORTH 07 DEGREES 42 MINUTES 31 SECONDS WEST, 34.29 FEET; THENCE NORTH 67 DEGREES 18 MINUTES 21 SECONDS EAST, 99.91 FEET; THENCE NORTH 65 DEGREES 33 MINUTES 36 SECONDS EAST, 68.39 FEET; THENCE NORTH 63 DEGREES 40 MINUTES 40 SECONDS EAST, 44.71 FEET; THENCE NORTH 79 DEGREES 45 MINUTES 55 SECONDS EAST, 52.69 FEET; THENCE NORTH 75 DEGREES 02 MINUTES 15 SECONDS EAST, 68.71 FEET; THENCE NORTH 67 DEGREES 53 MINUTES 30 SECONDS EAST, 83.65 FEET; THENCE NORTH 52 DEGREES 38 MINUTES 24 SECONDS EAST, 47.49 FEET; THENCE NORTH 25 DEGREES 35 MINUTES 15 SECONDS EAST, 28.51 FEET; THENCE NORTH 14 DEGREES 59 MINUTES 10 SECONDS EAST, 47.21 FEET; THENCE NORTH 08 DEGREES 20 MINUTES 15 SECONDS EAST, 69.69 FEET; THENCE NORTH 11 DEGREES 10 MINUTES 12 SECONDS EAST, 64.77 FEET; THENCE NORTH 21 DEGREES 16 MINUTES 17 SECONDS WEST, 95.68 FEET; THENCE NORTH 08 DEGREES 18 MINUTES 05 SECONDS WEST, 85.06 FEET; THENCE NORTH 03 DEGREES 24 MINUTES 35 SECONDS WEST, 83.30 FEET TO POINT A; THENCE NORTH 88 DEGREES 19 MIN UTES 41 SECONDS EAST, 226.92 FEET; THENCE SOUTH 88 DEGREES 40 MINUTES 28 SECONDS EAST, 949.93 FEET; THENCE SOUTH 53 DEGREES 59 MINUTES 01 SECONDS EAST, 66.20; THENCE SOUTH 51 DEGREES 11 MINUTES 58 SECONDS EAST, 51.60 FEET; THENCE SOUTH 58 DEGREES 10 MINUTES 24 SECONDS EAST, 78.99 FEET; THENCE SOUTH 39 DEGREES 53 MINUTES 49 SECONDS EAST, 47.30 FEET AND THERE TERMINATE. EASEMENT NUMBER 4: BEING PART THE SOUTHEAST QUARTER SECTION 20 AND PART OF THE SOUTHWEST QUARTER OF SECTION 21, TOWNSHIP 4 NORTH, RANGE 3 WEST OF THE FIRST PRINCIPAL MERIDIAN LOCATED IN PIKE TOWNSHIP, OHIO COUNTY, STATE OF INDIANA, AND BEING AN EASEMENT FOR INGRESS, EGRESS AND UTILITIES 50 FEET IN WIDTH, 25 FEET ON EACH SIDE OF A CENTERLINE DESCRIBED AS FOL LOWS: BEGINNING AT POINT A OF EASEMENT NUMBER 3 DESCRIBED ABOVE; THENCE ALONG THE CENTERLINE OF AN EASEMENT FOR IN GRESS AND EGRESS AND UTILITIES THE FOL LOWING 4 COURSES; THENCE SOUTH 88 DE GREES 30 MINUTES 20 SECONDS WEST, 74.49 FEET; THENCE SOUTH 77 DEGREES 28 MINUTES 07 SECONDS WEST, 57.82 FEET; THENCE SOUTH 68 DEGREES 43 MINUTES 11 SECONDS WEST, 51.99 FEET; THENCE SOUTH 85 DEGREES 19 MINUTES 38 SECONDS WEST, 46.01 FEET AND THERE TERMINATE. Tax Identification Number 58-04-21-300-002.007-002 More commonly known as: 15645 Deer Ridge Lane, Bennington, IN 47011 Together with rents, issues, income and profits, and without relief from valuation or appraisement laws. Eldon Fancher, Sheriff Ohio County, Indiana KRISOR & ASSOCIATES John D. Krisor, Jr. (5355-71) Brooks J. Grainger (19362·71) Ian M. Septoski (25450-64) Attorney at Law P.O. Box 6200 South Bend, IN 46660 (574) 272-1000 C-10-25-OCN-3t
SUMMONS-SERVICE BY PUBLICATION State of Indiana County of Ohio ss: Ohio Circuit Court Cause No. 58C01-1209-DR-26 In re the marriage of McDole; Luella Fay McDole vs. Keith McDole NOTICE OF SUIT The State of Indiana to the defendant and respondent above, and any other person who may be concerned. You are notified that you have been sued in the court above named. The nature of this suit against you is: Petition for Dissolution of Marriage. The summons by publication is specifically directed to the following named respondent whose whereabouts are unknown: Keith McDole. If you have a claim for relief against the plaintiff arising the same transaction or occurrence you must assert it in your written answer. You must answer the complaint in writing, by you or your attorney, on or before the 15th day of December, 2012, (the same being within thirty days after the third Notice) and if you fail to do so a judgment will be entered against you for what the plaintiff has demanded. Attest: Annie Jo Jackson Clerk of the Ohio Circuit Court P.O. Box 185 Rising Sun, IN (812) 438-2610 C-11-1-RSR-3t IN THE OHIO SUPERIOR COURT CAUSE NO. 58C01-1209-MF-0021 STATE OF INDIANA) SS. COUNTY OF OHIO GREEN TREE SERVICING LLC, Plaintiff .vs. MATTHEW HATCHER, PERSONAL REPRESENTATIVE FOR THE ESTATE OF JERRY L. HATCHER (NOW DECEASED), BRAD HATCHER, THE UN KNOWN HEIRS AND DEVISEES OF JERRY L. HATCHER (NOW DECEASED) AND 1ST FINANCIAL BANK, NATIONAL ASSOCIATION ) Defendants. GT-69 NOTICE OF SUIT The State of Indiana to the defendants named above and any other person or persons who may be concerned. You are notified that you have been sued in the Court named above. The nature of the suit against you is: Foreclosure of real estate mortgage on: Being part of the Southeast Quarter of Section 28, Township 4 North, Range 1 West of the First Principal Meridian located in Randolph Township, Ohio County, Indiana, and described as follows: Commencing at an iron pipe marking the Northeast corner of Southeast Quarter, Section 28, Township 4 North, Range 1 West; thence South 00 degrees 24 minutes 30 seconds West along the East line of said Section 28, 1007.48 feet to a railroad spike in the center of Salem Ridge Road; thence along said road the following seven courses: North 55 degrees 05 minutes 50 seconds West, 149.11 feet to a railroad spike; North 73 degrees 45 minutes 30 sec onds West, 223.30 feet to a railroad spike; North 84 degrees 43 minutes West, 161.75 feet to a railroad spike; South 77 degrees 39 minutes West, 242.68 feet to a railroad spike; North 88 degrees 54 min utes 20 seconds West, 114.17 feet to a railroad spike; North 76 degrees 00 minutes 40 seconds West, 428.79 feet to a railroad spike; North 75 degrees 34 minutes 20 seconds West, 665.11 feet to a railroad spike and the point of beginning; thence continuing along said road the following six courses: North 75 degrees 36 minutes 10 seconds West, 221.00 feet to a P.K. nail; North 67 degrees 28 minutes 10 seconds West, 97.60 feet to a P.K. nail; North 52 degrees 36 minutes 10 seconds West, 90.50 feet to a P.K. nail; North 38 degrees 51 minutes 50 seconds West, 75.37 feet to a P.K. nail; North 29 degrees 17 minutes 50 seconds West, 71.98 feet to a P.K. nail; North 21 degrees 09 minutes 10 seconds West, 65.68 feet to a P.K. nail; thence North 86 degrees 34 minutes 30 seconds East, 213.13 feet to an iron pipe; thence South 84 degrees 05 minutes 50 seconds East, 230.46 feet to an iron pipe; thence South 01 degrees 21 minutes 30 seconds West, 185.00 feet to an iron pipe; thence South 18 degrees 26 minutes 40 seconds East, 141.37 feet to the point of begining. Containing 2.39 acres, more or less. More commonly known as 3254 Salem Ridge Road, Rising Sun, Indiana 47040 This summons by publication is specifically di rected to the following named defendants whose whereabouts are unknown: 1st Financial Bank, N. A. and Brad Hatcher and Matthew Hatcher, Personal Representative for the Estate of Jerry L. Hatcher (now deceased) and Unknown Heirs and Devisees of Jerry L. Hatcher (now deceased) In addition to the above named defendants being served by this summons there may be other defendants who have an interest in this lawsuit. If you have a claim for relief against the plaintiff arising from the same transaction of occurence, you must assert it in your written answer. You must answer the Complaint in writing, by you or your attorney, within thirty (30) days after the third Notice of Suit is published, and if you fail to do so, a judgment will be entered against you for what the plaintiff has demanded. Annie Jo Jackson Clerk of the Ohio Superior Court John D. Cross,#29878-49 Mercer Belanger Chase Tower 111 Monument Cir., #3400 Indianapolis, IN 46204 (317) 636-3551 phone (317) 636-6680 fax NOTICE This is an attempt to collect a debt and any information obtained will be used for that purpose. This communication is from a debt collector. C-10-18-RSR-3t
Don’t miss an Issue!
812-537-0063
Subscribe to the
Rising Sun Recorder/Ohio County News
TODAY!
BIGGER! BETTER! FASTER!
The NEW Register Publications Websites! Exciting New Features! E-Editions • Blogs • & More!
www.REGISTERPUBLICATIONS.com